November 14, 2024

___________________________

LEGAL

_____________________________

CASE NO. CV-2024-903895

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO:LEONA C. SMITH (SPEARS), DECEASED AND HER HEIRS AND DEVISEES; JAMES DUDLEY SMITH, III, DECEASED AND HIS HEIRS AND DEVISEES; DES CAPITAL, LLC., TLR AL,LLC, US BANK, NATIONAL ASSOCIATION (INC.) AS SUCCESSOR IN INTEREST TO WACHOVIA-COLL AGT/SASS MUNI V;  J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF
BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties
claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 29, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  1561 Graymont Avenue W, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-33-3-005-016.000 a/k/a 0122003330050160000000

Legal Description: Lot 3, Block 4, according to the Survey of Ridgewood Park, as recorded in Map Book 14,
Page 55, in the Probate Office of Jefferson County, Alabama a/k/a LOT 3 BLK 4 RIDGEWOOD PARK.

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903911

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: EMMETT W. TURNER, AND HIS HEIRS AND DEVISEES, IF DECEASED, INTERNAL REVENUE
SERVICE; NETTIE TAYLOR AND HER HEIRS AND DEVISEES, IF DECEASED; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF
BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties
claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 30, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  1015 4th Court W, Birmingham, Alabama 35204

Tax Parcel ID No.:  22-00-33-4-026-014.000 a/k/a 01220033402601400000000

Legal Description: Lot 9, Block 13, according to the Highland Lake Land Co. Re-Survey of Parts of Blocks
12, 13, and 16, as recorded in Map Book 16, Page 30, in the Probate Office of Jefferson County, Alabama a/k/a LOT 9 BLK 13 HGHLD LAKE LD CO RESUR OF BLKS 12 13 & 16

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903913

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: MATILDA HAMPTON, DECEASED, AND HER HEIRS AND DEVISEES;  J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF
BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties
claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 30, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  1200 4th Avenue W, Birmingham, Alabama 35208

Tax Parcel ID No.:  29-00-04-2-001-014.000 a/k/a 0129000420010140000000

Legal Description: Lot 7, Block 28, according to the Survey of Compton as recorded in Map Book 1,
Page 83, in the Probate Office of Jefferson County, Alabama a/k/a LOT 7 BLK 28 COMPTON
RISING

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903703

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: RHONDA C. DUMAS AND HER HEIRS AND DEVISEES, IF DECEASED; ALVIN MAHAFFEY AND
HIS HEIRS AND DEVISEES, IF DECEASED; RESIDENTIAL FUNDING CORPORATION; J.T.
SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF
BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties
claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 12, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  3038 15th St. W, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-32-4-001-010.000 a/k/a 01220003240010100000000

Legal Description: Lot 10 and the West 25 feet of Lot 11, Block 2, according to the Survey of Oakhurst as recorded in Map Book 16, Page 7, in the Probate Office of Jefferson County, Alabama a/k/a LOT 10 and
& W 25 FT LOT 11 BLK 2 OAKHURST.

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903815

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: DAWOOD KHAN AND HIS HEIRS AND DEVISEES, IF DECEASED; TCMDF FAMILY LIMITED
PARTNESHIP; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 23, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  525 12th St. W, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-33-4-017-002.000 a/k/a 0122003340170020000000

Legal Description: Lot 26, Block 20, according to the Survey of Highland Lake Land Co.’s Resurvey
of Blocks 18 & 20, as recorded in Map Book 16, Page 61, in the Probate Office of Jefferson
County, Alabama a/k/a LOT 26 BLK 20 HGLD LAKE LAND CO RESUR OF BLKS 18 & 20

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903767

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: BOBBY LOWRY AND HIS HEIRS AND DEVISEES, IF DECEASED; MYRA LOWRY AND HER HEIRS AND DEVISEES, IF DECEASED; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 20, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  2525 Pike Road, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-32-3-035-002.000 a/k/a 0122003230350020000000

Legal Description: Parts of Lots 16, 17, and 18, in Block 79, according to the Survey of Birmingham-
Ensley, as recorded in Map Book 1, Page 245, in the Office of the Judge of Probate of Jefferson
County, Alabama more particularly described as follows:

Begin at the southeast corner of said lot 18 and run  thence northwardly along the east line thereof
for a distance of 82.20 feet to a point on the southeasterly line of Pike Road; run thence
southwestwardly along the southeasterly line of said road for a distance of 136.70 feet, more or
less, to a point on the south line of said Block 79, run thence eastwardly along said south line for
a distance of 113.20 feet to the point of beginning aka LOTS 16 17 18 BLK 79 LYING SE OF
PIKE RD BHAM ENSLEY LAND AND IMP CO.

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903809

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: MARY L. KILLIAN AND HER HEIRS AND DEVISEES, IF DECEASED; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 23, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address:  1322 4th Court W, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-33-3-024-010.000 a/k/a 01220033302400100000000

Legal Description: Lot 3, Block 12, according to the Survey of Compton, as recorded in Map Book 1,
Page 83, in the Probate Office of Jefferson County, Alabama a/k/a LOT 3 BLK 12 COMPTON RISING.

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903824

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: CAREY HARRIS AND HIS HEIRS AND DEVISEES, IF DECEASED; CARLETON P. KETCHAM, JR.;
J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 24, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 2730 17th Street, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-32-4-020-020.000 a/k/a 01220032402400200000000

Legal Description: Lot 3, Block 12, according to the Survey of Shadyside Park Addition to
Birmingham, as recorded in Map Book 13, Page 31, in the Probate Office of Jefferson County, Alabama
a/k/a LOT 3 BLK C SHADYSIDE PARK ADD TO BHAM

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903892

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: KENNIS OWENS (DECEASED) AND HER HEIRS AND DEVISEES; BAMA, LTD, INC.;
AMWEST FUNDING CORP.; RESIDENTIAL FUNDING CORPORATION; PNC BANK, NATIONAL
ASSOCIATION (FORMERLY COMPASS BANK); AMSOUTH BANK MORTGAGE COMPANY, INC
(FORMERLY AMSOUTH BANK OF ALABAMA); J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 28, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 6, 2024 at 9:30 A.M. at the Jefferson County Courthouse, Courtroom 670, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 2730 17th Street, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-32-4-020-020.000 a/k/a 01220032402400200000000

Legal Description: Lot 3, Block 12, according to the Survey of Shadyside Park Addition to
Birmingham, as recorded in Map Book 13, Page 31, in the Probate Office of Jefferson County, Alabama
a/k/a LOT 3 BLK C SHADYSIDE PARK ADD TO BHAM

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903912

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: ANTONIO GADDIS, AND HIS HEIRS AND DEVISEES, IF DECEASED; IN SOURCE FINANCIAL
SERVICES, LLC; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 30, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 804 4th Avenue W, Birmingham, Alabama 35204

Tax Parcel ID No.:  29-00-04-1-002-009.000 a/k/a 0129000410020090000000

Legal Description: Lot 19, Block 20, according to the Survey of Owenton as recorded in Map Book 2, Page 26, in the Probate Office of Jefferson County, Alabama
a/k/a LOT 19 BLK 20 OWENTON

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903825

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: RECARDO COOK, SR AND HIS HEIRS AND DEVISEES, IF DECEASED; CASSANDRA
COOK AND HER HEIRS AND DEVISEES; IF DECEASED; FIRST BAPTIST CHURCH JONESBORO HEIGHTS; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 24, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 932 4th Court W, Birmingham, Alabama 35203

Tax Parcel ID No.:  22-00-33-4-021-035.000 a/k/a 0122003340210350000000

Legal Description: Lot 12, Block 16, according to the Survey of Owenton as recorded in Map Book 2, Page 26, in the Probate Office of Jefferson County, Alabama a/k/a LOT 12 BLK 16 OWENTON

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903823

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: ROSEBUD CHAPPELL AND HER HEIRS AND DEVISEES, IF DECEASED; ANNIE HESTER
AND HER HEIRS AND DEVISEES, IF DECEASED; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 24, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 1604 8th Avenue W, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-33-3-004-023.000 a/k/a 0122003330040230000000

Legal Description: Lot 16, Block 1, according to the Survey of Ridgewood Park, as recorded in Map Book 14, Page 55, in the Probate Office of Jefferson County, Alabama a/k/a LOT 16 BLK 1 RIDGEWOOD PARK

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903896

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: EDWARD EUGENE SHIVER AND HIS HEIRS AND DEVISEES, IF DECEASED;
MARY LOU SHIVER AND HER HEIRS AND DEVISEES, IF DECEASED; MADGE W, LANGFORD,
DECEASED, AND HER HEIRS AND DEVISEES; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 29, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 2647 16th Street, Birmingham, Alabama 35208

Tax Parcel ID No.:  22-00-32-4-017-002.000 a/k/a 0122003240170020000000

Legal Description:  The North 100 feet of Lot 1 and the West 15 feet of the North 100 feet of Lot 2,
Resurvey of Block 20, Shady Side, as recorded in Map Book 15, Page 32, in the Probate Office of Jefferson County, Alabama a/k/a N 100 FT OF LOT 1 & W 15 FT OF N 100 FT OF LOT 2 RESUR OF BLK 2 SHADYSIDE POB 130.5 FT W OF SW INTER 16TH ST BARBOUR AVE TH W 65 FT ALG 16TH ST
S 100 FT TH E 65 FT TH N 100 FT TO POB

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903914

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: DIANE FOSTER A/K/A DIANE MCCONICO AND HER HEIRS AND DEVISEES, IF DECEASED; GERTIE THOMAS, DECEASED, AND HER HEIRS AND DEVISEES; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 30, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 112 Bankhead Highway N, Birmingham, Alabama 35204

Tax Parcel ID No.:  22-00-27-4-017-023.011 a/k/a 0122002740230110000100

Legal Description: Lot 1, according to Robertson’s Resurvey of Lot E, North Smithfield, as recorded
in Map Book 128, Page 33, in the Probate Office of Jefferson County, Alabama a/k/a
LOT 1 ROBERTSON’S RESUR OF LOT E NO SMITHFIELD RESUR 128/33

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

CASE NO. CV-2024-903893

THE BIRMINGHAM LAND BANK AUTHORITY, a Public Corporation,

NOTICE OF FINAL HEARING BY PUBLICATION

TO: THOMAS E. BADDLEY, JR. AS RECEIVER FOR COMMUNITY HOMEBANC, INC., MTG,
MTG SERVICES, LLC; J.T. SMALLWOOD, JEFFERSON COUNTY TAX COLLECTOR; JEFFERSON COUNTY, ALABAMA; CITY OF BIRMINGHAM, ALABAMA; and any and all other unknown heirs, claimants or interested parties claiming any right, title, estate, lien or interest in the real estate described herein,

The Birmingham Land Bank Authority (the “Land Bank”), a public corporation organized under the laws of the State of Alabama, filed a Petition to Quiet Title and Foreclosure (the “Petition”) on the property described herein on September 28, 2024, in the Circuit Court of Jefferson County and recorded a Notice of Pending Quiet Title and Foreclosure Action (the “Lis Pendens”) on October 28, 2024, in the Probate Court of Jefferson County, Alabama. Notice is hereby given that a final hearing was set to be heard on December 13, 2024 at  10:00 A.M. at the Jefferson County Courthouse, Courtroom 340, 716 Richard Arrington, Jr. Boulevard, North, Birmingham, Alabama 35203. The property that is the subject of this hearing is described as follows:

Property Address: 932 6th Avenue W, Birmingham, Alabama 35204

Tax Parcel ID No.:  22-00-33-4-006-008.000 a/k/a 012200334006080000000

Legal Description: Lot 12, Block 9, according to the Survey of Owenton as recorded in Map Book 128,
Page 33, in the Probate Office of Jefferson County, Alabama a/k/a LOT 12 BLK 9 OWENTON

ANY PERSON WITH A PROPERTY INTEREST IN THE ABOVE PROPERTY IS HEREBY NOTIFIED THAT THEY MAY LOSE SUCH INTEREST, IF ANY, AS A RESULT OF THE ABOVE-REFERENCED QUIET TITLE AND FORECLOSURE ACTION. The judgment of the Court may result in title to the property vesting in the Birmingham Land Bank Authority. Any person who proves to the Court’s satisfaction a right to redeem the property pursuant to Alabama Code 1975 §§ 40-10-83, et seq. may redeem the property pursuant to those statutes within five (5) days after the appropriate Order on Final Hearing is issued.  FAILURE TO REDEEM THE PROPERTY AND PRESENT PROOF OF REDEMPTION TO THE CIRCUIT COURT WITHIN THE FIVE-DAY PERIOD MAY RESULT IN A LOSS OF THE RIGHT OF REDEMPTION.

IT IS THEREFORE ORDERED by the undersigned Clerk of Court that publication of this notice be made once a week for three consecutive weeks in The Birmingham Times, a newspaper of general circulation in Jefferson County, Alabama, and that all persons to whom this notice is addressed and any and all persons claiming any title to, interest in, or lien or encumbrance on the above described land or any part thereof are here by directed to plead, answer or otherwise respond to the complaint in this cause before the hearing date or a judgment by default may be rendered against them it being intended that this notice shall be used to perfect service against all parties who cannot be personally served with a copy of this complaint.

The address of the Birmingham Land Bank Authority is City Hall, 710 20th Street North, Birmingham, Alabama 35203 and may be contacted care of the City of Birmingham Law Department at 205-254-2117.

Signed this 4th day of November, 2024

Jacqueline Anderson Smith, Circuit Clerk

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Williford Orman Construction LLC, Contractor, has completed the Contract for Construction of Fine Arts Addition and Renovation for Pelham High School, Package B: Culinary Lab Upgrade and Outdoor Cooking Addition at Pelham, AL for the State of Alabama and the City of Pelham, Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Lathan Associates Architects PC.

Williford Orman Construction LLC
PO Box 1985
Pelham, AL 35124

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that P & M Mechanical, Inc., Contractor, has completed the UAB Chauncey Sparks Center 6th Floor Neurology Renovation project, UAB Project #230103, for the Board of Trustees of the University of Alabama on behalf of the University of Alabama at Birmingham, Owner, located at 1720 7th Avenue South, Birmingham, AL 35233, and have made request for final settlement of said Contract.  All persons having any claim for labor, materials, or otherwise, in connection with this project, should immediately contact T.R. I. Architecture + Interior Design, LLC, 2627 Aberdeen Road, Birmingham, AL 35223.

P & M Mechanical, Inc.
325 Carson Road North
Birmingham, AL  35215

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended notice is hereby given that Willoughby Contracting Co., Inc., Contractor, has completed the Contract for Construction of Pratt City Phase I P.04041, Ave V & U, Court T, 4th Pl, 6th Ln, 6th Pl, 7th St for the State of Alabama and Jefferson County and the Birmingham Water Works, owner, and have made request for the final settlement of said contract.  All persons having any claim for labor, material, or otherwise in connection with this project should immediately notify Birmingham Water Works board (Architect/Engineer)

Willoughby Contracting Co., Inc.
Contractor
2550 Cone Drive
Birmingham, Al 35217

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended notice is hereby given that Willoughby Contracting Co., Inc., Contractor, has completed the Contract for Construction of Pratt City Phase 2 P.04040, Court A, Ave B ,C & E, 3rd Way, 5th Pl, 5th Way, 6th St, for the State of Alabama and Jefferson County and the Birmingham Water Works, owner, and have made request for the final settlement of said contract. All persons having any claim for labor, material, or otherwise in connection with this project should immediately notify Birmingham Water Works board (Architect/Engineer)

Willoughby Contracting Co., Inc.
Contractor
2550 Cone Drive
Birmingham, Al 35217

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Quality Architectural Metal & Roofing, Inc., Contractor, has completed the contract for the City of Bessemer for Improvement of B-1797-Roof Replacement for Bessemer Civic Center 2024 Emergency Roof Replacement, and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify, EEFS Company, PC 1930 2nd Avenue North, Suite 150, Bessemer, Alabama 35020 & Quality Architectural Metal & Roofing, Inc. 3107 2nd Avenue South Birmingham, AL  35233.

BT11/14/2024

______________________________

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Quality Architectural Metal & Roofing, Inc., Contractor, has completed the contract for JEFCO 2024 Re-Roofs for Bagley Elementary School, Bryan Elementary School, Pinson Elementary School for Jefferson County Board of Education at Birmingham, AL and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify TurnerBatson Architects, PC, Quality Architectural Metal & Roofing, Inc. 3107 2nd Avenue South Birmingham, AL  35233.

BT11/14/2024

____________________________

NOTICE TO CONTRACTORS

The City of Birmingham gives notice that sealed bids for the ARPA FUNDED Garrison Ave SW Drainage Improvements (ENG # 2024-015) project will be received by the City Engineer in Room 220, City Hall, Birmingham, Alabama until 2:00 pm (CDT) on Wednesday, November 20, 2024, at which time and place they will be publicly opened and read in Conference Room 220, 2rd Floor City Hall, Birmingham, Alabama. The award of this Contract will be made pursuant to Alabama Code: 39-1-1, et seq. (Public Works)

The City of Birmingham is a recipient of Coronavirus State and Local Fiscal Recovery Funds (“Fiscal Recovery Funds”) pursuant to the American Rescue Plan Act of 2021 (“ARPA”) and intends to fund, in part or in whole, the cost of this contract using Fiscal Recovery Funds. As such, the selected contractor must comply with the terms of ARPA, regulations issued by the U.S. Department of the Treasury (“Treasury”) governing the expenditure of monies distributed from the Fiscal Recovery Funds, the Award Terms and Conditions applicable to the Fiscal Recovery Funds, and such other guidance as Treasury has issued or may issue governing the expenditure of monies distributed from the Fiscal Recovery Funds.

All bidders must have a UEI (Unique Employee Identification) number issued by the U.S. General Services Administration to be eligible to bid on ARPA funded project. UEI numbers can be obtained by signing up at http://sam.gov. Website User Registration is not required to obtain a UEI number.

All bidders are required to submit a Debarment Form completed by a company principal and include it inside the sealed bid envelope. The bidders UEI number must be provided on the Debarment Form.

The primary Items of Work related to this project are:

18”x11” RCAP – 257 LF, Inlets (type varies) – 7 Each, Curb & Gutter (type varies) – 767 LF, 6” Concrete Paving (Driveways) – 82 SY, Asphalt Roadway Patching – 215 SY, Ditch/Swale Grading – 940 LF

Bid documents are open to public inspection in the Office of the City Engineer, Room 220 City Hall, 710 20th Street, North Birmingham, AL 35203.

Bid documents may be viewed and purchased through the City of Birmingham online plans room site at https://www.birminghamplanroom.com under the project name “ARPA FUNDED Garrison Ave SW Drainage Improvements”. Any cost for reproduction shall be the responsibility of bidders.

Prospective bidders are advised to check their source of bid documents frequently for any addenda to the bid documents. It is the bidder’s responsibility to bid on the correct set of bid documents.

Bids shall be accompanied by a cashier’s check drawn on an Alabama bank, or a bid bond executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama, in an amount equal to 5% of the bid (subject to a maximum of $10,000) and payable to the City of Birmingham. Bid bonds of the three (3) lowest bidders will be held for a period of ninety (90) days unless bidders agree, in writing, to a longer period of time.  No bid may be withdrawn after the scheduled closing time for receipt of bids and for a period of ninety (90) days thereafter.

A performance bond equal to 100% of the contract amount and a payment bond equal to 100% of the contract amount will be required of the successful bidder. Said bonds shall be executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama.

Liability insurance certificates shall be required of the successful bidder and such certificates shall list the City of Birmingham, its officials, agents, and employees as additional named insured.

Only bids submitted by General Contractors licensed in the State of Alabama in accordance with Title 34, Chapter 8 of the Code of Alabama (1975 as amended) will be considered.

Bids shall be submitted in a sealed envelope marked “SEALED BID – ARPA Funded Garrison Ave SW Drainage Improvements”. Contractors shall write his or her State of Alabama general contractor’s license number and the name of the company submitting the bid on the outside of the sealed bid envelope.

The sealed bid envelope shall contain the following documents: (1) the Form of Proposal, (2) the Authorization to execute the Form of Proposal, (3) bid bond, (4) MBE/DBE Form A, Form C, and Form D, (5) a copy of the Contractor’s State of Alabama General Contractor’s License, (6) the Contractor’s Completed Debarment Form, (7) and Addendum Acknowledgement.

Special attention is called to the applicability of the Birmingham Plan-Construction Industry Program to this project.  Under this Program the utilization of Minority Business Enterprises and Disadvantaged Business Enterprises (“MBE/DBE”) is encouraged.  The Construction Industry Authority establishes a system of floating MBE/DBE goals which may differ from year to year and project to project.  Overall, these goals shall not be less than the historical participation of MBE/DBE’s in construction projects of the City and its agencies.

Bidders may contact the Birmingham Construction Industry Authority (BCIA) to request additional information about the required MBE/DBE forms by contacting the Executive Director, Birmingham Construction Industry Authority at 601 37th Street South, Birmingham, AL, 35222; telephone (205) 324-6202 or info@bcia1.org.  For federally funded contracts, the provisions of the President’s Executive Order 11246 and federal agency regulations requiring affirmative action to achieve employment and utilization of minority persons and businesses, and the Davis-Bacon Act provisions are applicable.

As a matter of public policy, the City of Birmingham agrees to make opportunities available to the maximum extent possible, to actively include Historically Underutilized Business Enterprises (HUBE’s) such as architectural firms, engineering firms, investment banking firms, other professional consultant services providers, and construction contractors as part of business, economic and community revitalization programs.

It is the bidder’s responsibility to make sure that the bid is in the possession of the City Engineer on or before 2:00 pm, November 20, 2024. Bids received after this time will not be considered. Bids can be dropped into the Bid Box located in Room 220 of City Hall or delivered to the City Engineer in Room 220 City Hall.

A MANDATORY PRE-BID CONFERENCE will be held on November 13, 2024, at 3:00 pm in Room 220 of City Hall.

The City of Birmingham reserves the right to reject any or all bids and to waive any informality in any bid.

Jesse P. Miller, PE
City Engineer

BT11/14/2024

______________________________

NOTICE TO CONTRACTORS

The City of Birmingham gives notice that sealed bids for the ARPA FUNDED Hooper City Phase V project will be received by the City Engineer in Room 220, City Hall, Birmingham, Alabama until 10:00 AM. (CDT) on Friday, November 22nd, 2024, at which time and place they will be publicly opened and read in Conference Room 220, 2rd Floor City Hall, Birmingham, Alabama. The award of this Contract will be made pursuant to Alabama Code: 39-1-1, et seq. (Public Works)

The City of Birmingham is a recipient of Coronavirus State and Local Fiscal Recovery Funds (“Fiscal Recovery Funds”) pursuant to the American Rescue Plan Act of 2021 (“ARPA”) and intends to fund, in part or in whole, the cost of this contract using Fiscal Recovery Funds. As such, the selected contractor must comply with the terms of ARPA, regulations issued by the U.S. Department of the Treasury (“Treasury”) governing the expenditure of monies distributed from the Fiscal Recovery Funds, the Award Terms and Conditions applicable to the Fiscal Recovery Funds, and such other guidance as Treasury has issued or may issue governing the expenditure of monies distributed from the Fiscal Recovery Funds.

All bidders must have a UEI (Unique Employee Identification) number issued by the U.S. General Services Administration to be eligible to bid on ARPA funded project. UEI numbers can be obtained by signing up at http://sam.gov. Website User Registration is not required to obtain a UEI number.

All bidders are required to submit a Debarment Form completed by a company principal and include it inside the sealed bid envelope. The bidders UEI number must be provided on the Debarment Form.

The primary Items of Work related to this project are:

Base Bid: Retaining Wall (1,360 Square Feet), Crushed Stone Base (5,365 Square Yard), Asphalt Binder 2” Thick (596 Tons), 4” Concrete Sidewalk (901 Square Yards), 18” Curb and Gutter (3,521 Linear Feet), 18” RCP Class III (1,241 Linear Feet), Assorted Storm Inlets (15 Each)

Bid documents are open to public inspection in the Office of the City Engineer, Room 220 City Hall, 710 20th Street, North Birmingham, AL 35203.

Bid documents may be viewed and purchased through the City of Birmingham online plans room site at https://www.birminghamplanroom.com under the project name “ARPA Funded Hooper City Phase V”. Any cost for reproduction shall be the responsibility of bidders.

Prospective bidders are advised to check their source of bid documents frequently for any addenda to the bid documents. It is the bidder’s responsibility to bid on the correct set of bid documents.

Bids shall be accompanied by a cashier’s check drawn on an Alabama bank, or a bid bond executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama, in an amount equal to 5% of the bid (subject to a maximum of $10,000) and payable to the City of Birmingham. Bid bonds of the three (3) lowest bidders will be held for a period of ninety (90) days unless bidders agree, in writing, to a longer period of time.  No bid may be withdrawn after the scheduled closing time for receipt of bids and for a period of ninety (90) days thereafter.

A performance bond equal to 100% of the contract amount and a payment bond equal to 100% of the contract amount will be required of the successful bidder. Said bonds shall be executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama.

Liability insurance certificates shall be required of the successful bidder and such certificates shall list the City of Birmingham, its officials, agents, and employees as additional named insured.

Only bids submitted by General Contractors licensed in the State of Alabama in accordance with Title 34, Chapter 8 of the Code of Alabama (1975 as amended) will be considered.

Bids shall be submitted in a sealed envelope marked “SEALED BID – ARPA FUNDED Hooper City Phase V Contractors shall write his or her State of Alabama general contractor’s license number and the name of the company submitting the bid on the outside of the sealed bid envelope.

The sealed bid envelope shall contain the following documents: (1) the Form of Proposal, (2) the Authorization to execute the Form of Proposal, (3) bid bond, (4) MBE/DBE Form A, Form C, and Form D, (5) a copy of the Contractor’s State of Alabama General Contractor’s License, (6) the Contractor’s Completed Debarment Form, (7) and Addendum Acknowledgement.

Special attention is called to the applicability of the Birmingham Plan-Construction Industry Program to this project.  Under this Program the utilization of Minority Business Enterprises and Disadvantaged Business Enterprises (“MBE/DBE”) is encouraged.  The Construction Industry Authority establishes a system of floating MBE/DBE goals which may differ from year to year and project to project.  Overall, these goals shall not be less than the historical participation of MBE/DBE’s in construction projects of the City and its agencies.

Bidders may contact the Birmingham Construction Industry Authority (BCIA) to request additional information about the required MBE/DBE forms by contacting the Executive Director, Birmingham Construction Industry Authority at 601 37th Street South, Birmingham, AL, 35222; telephone (205) 324-6202 or info@bcia1.org.  For federally funded contracts, the provisions of the President’s Executive Order 11246 and federal agency regulations requiring affirmative action to achieve employment and utilization of minority persons and businesses, and the Davis-Bacon Act provisions are applicable.

As a matter of public policy, the City of Birmingham agrees to make opportunities available to the maximum extent possible, to actively include Historically Underutilized Business Enterprises (HUBE’s) such as architectural firms, engineering firms, investment banking firms, other professional consultant services providers, and construction contractors as part of business, economic and community revitalization programs.

It is the bidder’s responsibility to make sure that the bid is in the possession of the City Engineer on or before 10:00 AM November 22nd, 2024. Bids received after this time will not be considered. Bids can be dropped into the Bid Box located in Room 220 of City Hall or delivered to the City Engineer in Room 220 City Hall.

A MANDATORY PRE-BID CONFERENCE will be held on November 15th, 2024, at 10:00 AM. in Room 220 of City Hall.

The City of Birmingham reserves the right to reject any or all bids and to waive any informality in any bid.

Jesse P. Miller, PE
City Engineer

BT11/14/2024
______________________________

ADVERTISEMENT FOR A/V FIRM REQUEST FOR STATEMENT OF QUALIFICATIONS

DATE: November 7, 2024
FROM: Jefferson County Commission
General Services Department, Room 1
716 Richard Arrington Jr. Blvd. North
Birmingham, Alabama 35203

RE: REQUEST FOR QUALIFICATIONS

The General Services department on behalf of the Jefferson County Commission is conducting the A/V Firm services selection process for the described Project.

PROJECT TITLE: Jefferson County Coroner/Medical Examiner Office Audio Visual System Design
PROJECT LOCATION:  100 Leaf Lake Blvd, Birmingham, Alabama 35211
PROJECT ESTIMATED CONSTRUCTION BUDGET: TBD

DEADLINE FOR SUBMISSIONS:  December 5, 2024, 2:00 P.M.

This project involves turnkey professional services for the design and implementation of Audio-Visual (A/V) solutions at the Jefferson County Coroner/Medical Examiner Office. The scope includes A/V systems for a training room, conference room, and five office CCTV monitors, covering design, bid preparation, bid assistance, and installation management.

General requirements:  The A/V Firm shall be responsible for the professional quality, technical accuracy, and coordination of the design work.  The A/V Firm will coordinate with the Architect and Contractor on the design and installation of the A/V systems.

The A/V Firm shall coordinate with the appropriate public utility companies and commissions, if required, to prepare connection designs according to the applicable guidelines. Submissions shall be prepared (and revised and resubmitted, if necessary) for securing approvals, class of service, permits, and service hook-ups.

The work shall comply with all applicable City of Birmingham, Jefferson County, State of Alabama, federal codes and regulations.  The work shall also comply with any applicable utility provider, construction industry and ASHRAE standards, requirements, and guidelines.

The work shall conform with the “to be established” project budget and scope, once finalized, throughout planning, design, and installation.

The AV Firm shall make site visits, attend meetings, produce meeting minutes, make presentations, and submit required deliverables as necessary to execute specific parts of the work ‘to be established’ and in the Contract and the Scope of Work for the project. The A/V Firm will be available to perform optional installation phase services at the agreed upon rate, if requested by the Jefferson County Commission.

If you would like to be considered for this Project, please provide one (1) complete copy of your documentation to our office by the deadline indicated above.  Minority, women and disabled veteran-owned enterprises (DBE) are encouraged to apply. Significant local participation is recommended for services for firms outside the State of Alabama. All qualification submissions shall be made in hard copy, bound 8 1/2 x 11 format.  Electronic files may be submitted in addition to hard copy.  Electronic submissions are to be in PDF format transmitted via a USB drive delivered to our office by the deadline indicated above. Electronic files are not required but are preferred.

Please include the following items in your packet:

Identify each specific qualification request identifiable by associated item numbers and tabbed accordingly below:

Qualification Package

1. Approach. A general statement of the firm’s approach with particular focus on distinguishing characteristics or services.

2. Work proposed to be performed. A discussion of the firm’s understanding of the scope of services to be provided and the major work tasks to be performed.

3. Key personnel. A list of the proposed project team assigned to this project and their roles, previous related experience, education, and date that person joined the firm.

4. Relevant experience. A statement of the firm’s relevant experience, including a brief description of projects similar in scope and size as the proposed project, include project title, dates work was performed, construction value, and client contact information.

5. Certificate of Insurance. Submit a copy of the firm’s certificate of insurance.

6. Include statement of DBE status. Is your firm a “Disadvantaged Business Enterprise”; Minority, women or disabled veteran-owned enterprise? Include statement of DBE status for each identified sub consultant/engineer listed for each package if applicable.

All questions regarding this project and submittal of the Statement of Qualifications shall be directed to Andy Olds, Committee Chair at email address andy.olds@jccal.org. Any contact with the selection committee team members other than Mr. Olds or his designee may disqualify the firm’s proposal from consideration.

BT11/14/2024

______________________________

ADVERTISEMENT for BIDDER PRE-QUALIFICATION
And NOTICE of INTENT to RECEIVE BIDS
from PREQUALIFIED BIDDERS

Pre-qualification submittals will be received by the Owner’s Representative/Project Manager,
Darren Kruty on behalf of Office of the Chief Facilities Officer, UAB Medicine, University of Alabama at Birmingham, and the University of Alabama Board of Trustees at UAB Hospital Planning, 2020 University Blvd., Birmingham, AL 35249 until 4:00 PM Central Time, Wednesday, November 27, 2024.  The original
and two (2) flash drives with duplicates of submittals are required for pre-qualification approval; however, email transmission copies may be transmitted to the Project Manager at dkruty@uabmc.edu and copied to rachelh@bparchitects.com to expedite the review process with a hard-copy of the submittal and two flash drives to be delivered within 24 hours.

UAB HOSPITAL – WIC 3rd Floor Labor & Delivery Infant Stations
For The
University of Alabama at Birmingham
Birmingham, Alabama
UAB Project No.: H235014

A. SCOPE OF WORK:

The project consists of renovation of  seventeen (17) Labor and Delivery Room Infant Stations, replacement of overbed lights, and new room medgas valves. The project will be broken into multiple phases. The scope of work includes, but is not limited to ceilings, finishes, plumbing, electrical work, and equipment coordination. The construction budget is anticipated to be between $800,000 – $1.2 Million.

The work will be performed under a single Prime General Contractor who will coordinate the work of this project. Particular and specific care will be required to coordinate complex shutdowns, limit disturbances and follow strict Infection Control and Interim Life Safety Measures (ICRA/ILSM) requirements for the protection of patients, family, and staff. The Prime General Contractors seeking to be pre-qualified will require experience with similar size and type hospital projects performed in and adjacent to an operating hospital environment and with the implementation and maintenance of infection control measures, interim life safety measures, coordinating shutdowns, and maintaining a clean and organized job site in an operating hospital. The General Contractor must have experience with representative projects as a General Contractor (not as a Construction Manager, Program Manager, etc.)

B. PRIME CONTRACTOR BIDDER PRE-QUALIFICATIONS:

Prime contractor bidders interested in submitting a proposal must apply for pre-qualification and must be licensed under the Provision of Title 34, Chapter 8, and Code of Alabama, 1975. A copy of current Alabama Contractors license is to be included in pre-qualification submittal.

Only prime contractor bidders who have completed the pre-qualification process and that have been approved will be eligible to submit a bid/perform work for the Project.  Prospective Bidder’s Pre-qualification Package must be received by the Owner’s Project Manager no later than 4:00 PM Central Time, November 27, 2024 after which no further requests will be considered.

Pre-qualification Requirements Information Package may be obtained from the Architect upon letterhead request. Any addendums to the prequalification requirements will be issued to documented prime contractors only.

The pre-qualification procedure is intended to identify responsible and competent prime contractor bidders relative to the requirements of the Project.  Each prospective prime contractor bidder will be notified of the results of the pre-qualification, on or about December 2, 2024.

The Owner reserves the right to waive technical errors in applications, extend or abandon the pre-qualification process, should the interests of the Owner appear to be promoted thereby.

Progress Design and Construction Documents:
Prior to the pre-qualification deadline, project progress plans and specifications may be examined at the following location:

Architect:
Birchfield Penuel Architects
2805 Crescent Avenue, Suite 200
Birmingham, Alabama  35209
Ms. Alicia Pughsley
205-870-1876
aliciap@bparchitects.com

C. BIDS BY PRE-QUALIFIED PRIME GENERAL CONTRACTOR BIDDERS

Documents:
After notice to pre-qualified bidders is given, the pre-qualified prime contractor bidders may obtain bid documents from the Architect (see address above) upon deposit of $100.00 per set. The deposit is refundable in full on the first two (2) sets issued to each prime general contractor bidder upon return of documents in reusable condition within ten (10) days after bid opening. Additional sets for pre-qualified prime contractor bidders, subcontractors, vendors, or dealers may be obtained upon payment of the same deposit. The deposit for additional sets shall be refunded less the cost of printing, reproduction, handling and distribution, upon return of the documents in reusable condition within ten (10) days after bid opening.

Bid documents will be available at the following locations after notice to pre-qualified bidders is given.  Drawings and specifications may be examined at the Office of the Architect; and electronically at ConstructConnect and Dodge Data & Analytics.

Bonds:
A certified check or bid bond payable to the University of Alabama at Birmingham in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000 must accompany the bidder’s proposal.  Performance and Statutory Labor and Material Payment Bonds will be required at the signing of the Contract.

Bids:
Bids must be submitted on proposal forms or copies thereof furnished by the Architect. No bid may be withdrawn after the scheduled closing time for receipt of bids for a period of ninety (90) days.  The Owner reserves the right to reject bids if such action is determined to be in the best interest of the Owner.  The Owner reserves the right to revoke pre-qualification of any bidder in accordance with Section 39-2-12, Code of Alabama, 1975, as amended in 1997 (by Act 97-225). The Bid Date is December 19, 2024 at 2:00 PM Central Time at the University of Alabama at Birmingham, UAB Hospital Planning, 2020 University Blvd., Birmingham, Alabama 35294. Bids shall be clearly identified on the exterior of the package with the bidder’s name, address, State license number, the name of the project being bid, time and place of the bid opening. Sealed bids shall be properly identified.

Proposals may be hand delivered or received by mail on the date of the bid opening at the Office of Darren Kruty, Project Manager Facilities and Capital Projects, 2020 Building, 2020 University Blvd, Birmingham, Alabama 35233, until 12:00 noon.  After 12:00 noon of the date of the bid opening, proposals must be hand delivered and presented at the bid opening.  Sealed proposals shall be submitted in triplicate and shall be properly identified. All proposals received after 2:00 p.m. on
December 19, 2024 will be returned unopened.

Fire Alarm Work
In accordance with Title 34, Chapter 33A, of the Code of Alabama 1975, bidders for fire alarm work of this project, if any, must include with their bid, evidence of licensure as required by the act, by including with the bid submittal, a valid State Fire Marshal’s permit.

D. PRE-BID CONFERENCE
A mandatory Pre-Bid Conference will be held Wednesday, December 4, 2024 at 10:00 am at UAB Hospital Facilities, 2020 University Blvd., Birmingham, Alabama 35233. It is mandatory that all pre-qualified prime contractor bidders attend the Pre-Bid Conference.

BT11/14/2024

______________________________

NOTICE TO BIDDERS

WESTERN FILTER PLANT SODIUM HYPOCHLORITE CONVERSION, LIQUID LIME AND ELECTRICAL UPGRADES

Project Number: P.03696
Capital Budget Number: BP-658-20

Sealed Bids for the construction of the Western Filter Plant Sodium Hypochlorite Conversion, Liquid Lime and Electrical Upgrades will be received by The Water Works Board of the City of Birmingham Engineering Department, Attn: Hattye McCarroll. P.E.; Chief Engineer, 3600 First Avenue North, Birmingham, Alabama 35222 until 10:00 a.m. local time on Thursday December 12, 2024. Bids received after said time will be rejected and returned unopened.

Construction of a new sodium hypochlorite
1. New Bulk Sodium Hypochlorite Building
a. Sodium Hypochlorite Storage Area with grated access platforms above containment area.
b. Bulk sodium hypochlorite storage tanks, day tanks and access platforms.
c. Removable skylight access panels for tank removal.
d. Sodium Hypochlorite metering, transfer, and sump pumps.
e. Chemical Piping and valves.
f. Electrical Room.
g. Mechanical Room with HVAC equipment for the building.

2. New interior and exterior sodium hypochlorite piping and injection points. Containment piping with carrier tubing extends from new building to existing chemical injection points throughout the site. Chemical vaults are to be installed along piping runs to facilitate installation and replacement of chemical tubing.

3. New Liquid Lime Storage and Feed system in new outdoor concrete containment area

1. Liquid Lime storage tanks.
2. Liquid Lime pump enclosure with transfer pumps, feed pumps, power and control panels, safety shower, and sump pumps.

4. New Liquid Lime Truck Unloading Station with LCS, remote from new outdoor containment area.

5. New interior and exterior liquid lime piping, tubing, injection points, and junction boxes. Containment piping with carrier tubing extends from new containment area to existing chemical injection points at the rapid mix and clearwells. Chemical junction boxes are to be installed along piping runs to facilitate installation and replacement of chemical tubing.

6. New MCC equipment in the Electrical Room to replace existing MCC equipment in existing plant’s Chemical Building. New power feed from Filter Building to New Sodium

Hypochlorite Building.

7. New potable water line feeding the new Sodium Hypochlorite Building and additional fire hydrant connections.
8. Replacement of existing water heater beneath alum storage tank, installation of new tempered water valve, and new interior and exterior piping for hot and tempered water.
9. Demolition of old chlorine feed equipment, piping, scales, and scrubber system.
10. Demolition of old MCC’s in Chemical Building.
11. Demolition of old lime storage and feed equipment in the Chemical Building. Repair of Chemical Building roof after removal of old lime silo.
12. New DCS equipment in Sodium Hypochlorite Building and in Chemical Buildings.

13. Temporary power requirements for Carbon Building and new permanent power.
14. Modifications to electrical distribution at field motors, including disconnects, local control stations, and motor terminations.
15. Electrical improvements including video cameras, back boxes, and access control system.
16. Miscellaneous site improvements, electrical duct banks, conduits, and site piping as required.
17. Other miscellaneous associated items as necessary to complete the work.

Bids shall be based on a lump sum plus additional unit price items as indicated in the Bid Form.

Bidding Documents may be examined at the office of the Chief Engineer of The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, AL; and the office of Arcadis U.S., Inc., 1143 1st Ave. South, Birmingham, AL.

Prime Contractor bidders may obtain one complete set of Bidding Documents on or after October 29, 2024, from the office of the Chief Engineer of The Water Works Board of the City of Birmingham upon payment of $300.00 deposit by company check or by certified check and signing a nondisclosure statement. No personal checks or any other form of payment except as noted will be accepted. This deposit shall be refunded in full to each prime contractor bidder upon the return of the Bidding Documents in a reusable condition within 10 days after the bid opening. Additional sets of Bidding Documents for prime contractor bidders, subcontractors, vendors or dealers may be obtained upon payment of said $300.00 deposit and signing a nondisclosure statement. This deposit shall be refunded less the costs of printing, reproduction, handling, and distribution, upon return of the documents in reusable condition within 10 days after the bid opening. Company check or Certified check for documents shall be made payable to The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, Alabama, 35222 and mailed to the Attn: Hattye McCarroll P.E.; Chief Engineer. No additional charge will be made for delivery via UPS ground. Those requesting shipment of documents via carriers other than UPS ground will be made at the requesting firm’s expense. Partial sets of Bidding Documents will not be available to any Bidder. Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources. No Bidder may withdraw or alter a bid within 60 calendar days after the actual date of the bid opening.

A mandatory pre-bid conference and site visit, will be held at 9:00 a.m. local time on Tuesday, November 12, 2024 at the OWNER’s Western Filter Plant , located at 1400 Bankhead Highway,

Birmingham, Alabama 35214. All prospective Bidders and interested parties are required to attend the pre-bid conference and the pre-bid site visit. The purpose of the pre-bid conference and site visit is to raise questions pertaining to the Bidding and Contract documents and for the OWNER or its representatives to clarify any points. Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the mandatory Pre-Bid Conference.

This project includes a Preconstruction Planning Period that begins when the Contract Times commence. Construction Work onsite will not be allowed until completion of the Preconstruction Planning Period. The Preconstruction Planning Period is set forth in the Agreement.

Each bid shall be accompanied by a cashier’s check, drawn on an Alabama Bank, or bid Bond in the amount of five percent (5%) of the bid not to exceed $50,000.00 in the form and subject to conditions provided for in the Specifications.

The successful Bidder will be required to furnish a Performance Bond and a Payment Bond each in an amount equal to 100 percent of the Contract Award.

Bidders shall comply with all statutory requirements in accordance with the Instructions to Bidders. Bids will only be received from Contractors who are licensed by the State of Alabama.

Contract time of commencement and completion will be in accordance with the Agreement.

The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects. To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on racial, gender, social, or economic status.

It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.

Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.

Alabama Code §31-13-9 (1975) provides that as a condition for the award of any contract by The Water Works Board of the City of Birmingham, a business entity or employer that employs one or more employees within the state of Alabama shall provide documentation of enrollment in the E-Verify program.

Each Prospective Bidder must complete, as a condition for the award of any Contract by The Water

Works Board of the City of Birmingham, the Certification Regarding Debarment in Section 00201. The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Legislature of Alabama Act 2013-205 grants the Alabama Department of Revenue (ADOR) the authority to issue certificates of exemption from sales and use taxes for construction projects for certain governmental agencies. Pursuant to Act 2013-205, Section 1(g) the Contractor accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax- Attachment to BWWB Bid Form. Failure to provide an accounting of sales tax shall render the bid non-responsive. Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder. After Notice of Award, Contractor and Subcontractor licensed by the State Licensing Board for General Contractors must comply with ADOR requirements for making application for qualification of the exemption and are responsible for ADOR reporting requirements for the duration of the project.

If a Contract is to be awarded, it will be awarded to the Bidder with the best price on the best terms for the OWNER, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the Project and will result in the lowest overall cost to the OWNER for completion of the project. If a Contract is to be awarded, it will be awarded within 90 calendar days after the day of the opening of bids.

The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.

Owner:
The Water Works Board of the City of Birmingham 3600 First Avenue North
Birmingham, Alabama 35222
Hattye McCarroll, P.E
Telephone number (205) 244-4182

Engineer:
ARCADIS, U.S., Inc.
1143 1st Ave South, Suite 109
Birmingham, Alabama 35233
Mr. Dhiraj Parekh, P.E
Telephone number (205) 930-5956

BT11/14/2024

______________________________

NOTICE TO BIDDERS

THE WATER WORKS BOARD OF THE CITY OF BIRMINGHAM

HILLANDALE DRIVE / RUTLEDGE WAY
Project Number(s):  P.04421
Capital Budget Number(s):  1D & 1E

Sealed Bids for a water main replacement project will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Wednesday, December 11, 2024. The Sealed Bids will be opened and read at 10:00 a.m. local time on Wednesday, December 11, 2024, by System Development Department staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama.  Each Prospective Bidder will be able to listen to the Bid Opening via conference call [Number: 1-888-278-0296 / Access Code: 2875407].  Bids received after 9:00 a.m. local time on date aforementioned will be rejected and returned unopened.

** The Water Works Board of the City of Birmingham will award WIFIA Set #1 which includes (1) Grasselli Avenue SW / Doby Avenue SW (P.04207); (2) Brenda Avenue SW / Alvin Avenue SW (P.04391); and (3) Hillandale Drive / Rutledge Way (Fairfield) (P.04421) to a “single” Bidder based upon the total cost of the three (3) individual main replacement projects.

The Work consists of but is not limited to the installation of approximately 2,900’ of 6” DICL “Zinc Coated” pipe; 3,720’ of 4” DICL “Zinc Coated” pipe; 400’ of 2” Municipex (PEXa) pipe; and 125 water services” and other miscellaneous associated items as necessary to complete the Work along Hillandale Drive; Rutledge Drive; Rutledge Way; Glenfield Road; Glen Oaks Drive; Glen Oaks Circle; Oakland Drive; Oakview Circle; Glen Crest Circle; Swann Drive; Park Circle and Owen Avenue located in the City of Fairfield, Alabama.

Bids shall be based on unit price items and lump sum items as indicated on the Bid Form (Section 00410).

Bidding Documents may be examined at the office of the Manager – System Development Department, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.

Bidders may obtain one (1) complete set of Bidding Documents from the office of the Manager -System Development Department, The Water Works Board of the City of Birmingham.  Partial sets of Bidding Documents will not be available to any Bidder.  Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources.  No Bidder may withdraw or alter his bid within ninety (90) calendar days after the actual date of the Bid Opening.

A Mandatory Pre-Bid Conference will be held at 10:40 a.m. local time on Tuesday, November 19, 2024, in person in the Meter Shop Conference Room.  All Prospective Bidders are required to attend the Pre-Bid Conference.  The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points.  Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference in person.  HUB Program Acknowledgement (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Resource Engagement Form (HUB Form 3), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.

Each Prospective Bidder is required to visit the site(s) at which the Work is to be performed.  The OWNER will not conduct a site visit with the Prospective Bidders.

Each Bid shall be accompanied by a certified check or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in Section 00435, Bid Bond.

The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.

Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders.  Bids will only be received from CONTRACTORS who are licensed by the State of Alabama.

Contract time of commencement and completion will be in accordance with the Agreement.

The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects.  To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on social or economic status.  Historically Underutilized Business (HUB): a business formed for the purpose of making a profit and is at least 51% owned, operated and/or controlled by one or more American citizens or permanent resident aliens who are a: Minority Business Enterprise (MBE); Women Business Enterprise (WBE); or Disadvantaged Business Enterprise (DBE) [herein sometimes collectively referred to as a HUB].

It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.

Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.

Alabama Code §31-13-9 (1975) provides that as a condition for the award of any Contract by The Water Works Board of the City of Birmingham (“BWWB”), a business entity or employer that employs one or more employees within the State of Alabama shall provide documentation of enrollment in the E-Verify program.

Each Prospective Bidder must complete Section 00200a Certification Regarding Debarment.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200b Certification Regarding Lobbying Restrictions.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200c Certification Regarding Civil Rights Obligations.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200d Certification Regarding EEO Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200e Certification Regarding AIS Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200f Certification Regarding Telecon and Video Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must comply with Section 00452 Non-Discrimination Policy, while conducting business or participating in events or activities for the OWNER.  Each Prospective Bidder shall maintain an environment free of discrimination, harassment, and retaliation at all times.

Each Prospective Bidder must read, understand, and adhere to the requirements of Section 00740 Wage Determination Schedule relative to the minimum prevailing wage rates mandated by the applicable state labor department or other authority having jurisdiction (NO EXCEPTIONS).  Each Prospective Bidder is required to make sure his or her Subcontractor(s) understand the minimum prevailing wage rates for the work location.

Each Prospective Bidder must read and provide documentation relative to the “Request for Company Product and Service Information Letter” and complete the “EEO Report Form” document for the corporation, partnership, joint venture, etc. submitting a bid included at the end of the Section 00200 Instruction to Bidders.  These two (2) items must be included with the Prospective Bidder’s Bid.

Each Prospective Bidder shall read and understand the Alabama Department of Revenue’s (ADOR’s) sales and use tax exemption policy pursuant to Act 2013-205 Section 1(g)  [CONTRACTOR accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax – Attachment to BWWB Bid Form].  Failure to provide an accounting of sales tax shall render the Bid non-responsive.  Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder.  After Notice of Award, Prime Contractor and Subcontractor(s) licensed by the State Licensing Board for General Contractors must comply with ADOR reporting requirements for the duration of the project.  For further information see Section 00409, Alabama Department of Revenue-Sales and Use Tax Exemption, Section 00200 Instruction to Bidders (Article 33) and refer to paragraph 6.10 in the Supplementary Conditions.

If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the project and will result in the lowest overall cost to the OWNER for completion of the project.  Unless extended by OWNER, a Contract will be awarded within ninety (90) calendar days after the day of the opening of Bids.

The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.

Owner:
The Water Works Board of the City of Birmingham
3600 First Avenue North
Birmingham, Alabama 35222

Primary Contact:
Ms. Janice Acoff
Telephone: (205) 244-4265
Facsimile: (205) 244-4765
E-mail: janice.acoff@bwwb.org

Secondary Contact:
Mr. Douglass W. Stockham, IV, P.E.
Telephone: (205) 244-4186
Facsimile: (205) 244-4686
E-mail: doug.stockham@bwwb.org

BT11/14/2024

______________________________

NOTICE TO BIDDERS

THE WATER WORKS BOARD OF THE CITY OF BIRMINGHAM

BRENDA AVENUE SOUTHWEST / ALVIN AVENUE SOUTHWEST

Project Number(s):  P.04391

Capital Budget Number(s):  1D & 1E

Sealed Bids for a water main replacement project will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Wednesday, December 11, 2024.  The Sealed Bids will be opened and read at 10:30 a.m. local time immediately after the 2nd Project in WIFIA Set #1 on Wednesday, December 11, 2024, by System Development Department staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama.  Each Prospective Bidder will be able to listen to the Bid Opening via conference call [Number: 1-888-278-0296 / Access Code: 2875407].  Bids received after 9:00 a.m. local time on date aforementioned will be rejected and returned unopened.

** The Water Works Board of the City of Birmingham will award WIFIA Set #1 which includes (1) Grasselli Avenue SW / Doby Avenue SW (P.04207); (2) Brenda Avenue SW / Alvin Avenue SW (P.04391); and (3) Hillandale Drive / Rutledge Way (Fairfield) (P.04421) to a “single” Bidder based upon the total cost of the three (3) individual main replacement projects.

The Work consists of, but is not limited to the installation of approximately 1,200’ of 8” DICL “Zinc Coated” pipe; 2,850’ of 6” DICL “Zinc Coated” pipe; 950’ of 4” DICL “Zinc Coated” pipe; and 57 water services and other miscellaneous associated items as necessary to complete the Work along Brenda Avenue Southwest; Alvin Avenue Southwest; 39th Street Southwest; Felix Avenue Southwest; Spaulding Street Southwest; and Horace Street Southwest (Crawford Street Southwest), located in the City of Birmingham, Alabama.

Bids shall be based on unit price items and lump sum items as indicated on the Bid Form (Section 00410).

Bidding Documents may be examined at the office of the Manager – System Development Department, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.

Bidders may obtain one (1) complete set of Bidding Documents from the office of the Manager -System Development Department, The Water Works Board of the City of Birmingham.  Partial sets of Bidding Documents will not be available to any Bidder.  Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources.  No Bidder may withdraw or alter his bid within ninety (90) calendar days after the actual date of the Bid Opening.

A Mandatory Pre-Bid Conference will be held at 10:20 a.m. local time on Tuesday, November 19, 2024, in person in the Meter Department Conference Room, 1st Floor Main Office Building (3600 1st Avenue North).  All Prospective Bidders are required to attend the Pre-Bid Conference. The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points.  Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference via conference call.  HUB Program Acknowledgement (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Resource Engagement Form (HUB Form 3), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.

Each Prospective Bidder is required to visit the site(s) at which the Work is to be performed.  The OWNER will not conduct a site visit with the Prospective Bidders.

Each Bid shall be accompanied by a certified check or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in Section 00435, Bid Bond.

The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.

Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders.  Bids will only be received from CONTRACTORS who are licensed by the State of Alabama.

Contract time of commencement and completion will be in accordance with the Agreement.

The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects.  To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on social or economic status.  Historically Underutilized Business (HUB): a business formed for the purpose of making a profit and is at least 51% owned, operated and/or controlled by one or more American citizens or permanent resident aliens who are a: Minority Business Enterprise (MBE); Women Business Enterprise (WBE); or Disadvantaged Business Enterprise (DBE) [herein sometimes collectively referred to as a HUB].

It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.

Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.

Alabama Code §31-13-9 (1975) provides that as a condition for the award of any Contract by The Water Works Board of the City of Birmingham (“BWWB”), a business entity or employer that employs one or more employees within the State of Alabama shall provide documentation of enrollment in the E-Verify program.

Each Prospective Bidder must complete Section 00200a Certification Regarding Debarment.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200b Certification Regarding Lobbying Restrictions.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200c Certification Regarding Civil Rights Obligations.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200d Certification Regarding EEO Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200e Certification Regarding AIS Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200f Certification Regarding Telecon and Video Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must comply with Section 00452 Non-Discrimination Policy, while conducting business or participating in events or activities for the OWNER.  Each Prospective Bidder shall maintain an environment free of discrimination, harassment, and retaliation at all times.

Each Prospective Bidder must read, understand, and adhere to the requirements of Section 00740 Wage Determination Schedule relative to the minimum prevailing wage rates mandated by the applicable state labor department or other authority having jurisdiction (NO EXCEPTIONS).  Each Prospective Bidder is required to make sure his or her Subcontractor(s) understand the minimum prevailing wage rates for the work location.

Each Prospective Bidder must read and provide documentation relative to the “Request for Company Product and Service Information Letter” and complete the “EEO Report Form” document for the corporation, partnership, joint venture, etc. submitting a bid included at the end of the Section 00200 Instruction to Bidders.  These two (2) items must be included with the Prospective Bidder’s Bid.

Each Prospective Bidder shall read and understand the Alabama Department of Revenue’s (ADOR’s) sales and use tax exemption policy pursuant to Act 2013-205 Section 1(g)  [CONTRACTOR accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax – Attachment to BWWB Bid Form].  Failure to provide an accounting of sales tax shall render the Bid non-responsive.  Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder.  After Notice of Award, Prime Contractor and Subcontractor(s) licensed by the State Licensing Board for General Contractors must comply with ADOR reporting requirements for the duration of the project.  For further information see Section 00409, Alabama Department of Revenue-Sales and Use Tax Exemption, Section 00200 Instruction to Bidders (Article 33) and refer to paragraph 6.10 in the Supplementary Conditions.

If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the project and will result in the lowest overall cost to the OWNER for completion of the project.  Unless extended by OWNER, a Contract will be awarded within ninety (90) calendar days after the day of the opening of Bids.

The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.

Owner:
The Water Works Board of the City of Birmingham
3600 First Avenue North
Birmingham, Alabama 35222

Primary Contact:
Mr. Douglass W. Stockham, IV, P.E.
Telephone: (205) 244-4186
Facsimile: (205) 244-4686
E-mail: doug.stockham@bwwb.org

Secondary Contact:
Ms. Janice Acoff
Telephone: (205) 244-4265
Facsimile: (205) 244-4765
E-mail: janice.acoff@bwwb.org

BT11/14/2024

______________________________

NOTICE TO BIDDERS

THE WATER WORKS BOARD OF THE CITY OF BIRMINGHAM

GRASSELLI AVENUE SOUTHWEST / DOBY AVENUE SOUTHWEST

Project Number(s):  P.04207

Capital Budget Number(s):  1D & 1E

Sealed Bids for a water main replacement project will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Wednesday, December 11, 2024.  The Sealed Bids will be opened and read at 10:15 a.m. local time immediately after the 1st Project in WIFIA Set #1 on Wednesday, December 11, 2024, by System Development Department staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama.  Each Prospective Bidder will be able to listen to the Bid Opening via conference call [Number: 1-888-278-0296 / Access Code: 2875407].  Bids received after 9:00 a.m. local time on date aforementioned will be rejected and returned unopened.

** The Water Works Board of the City of Birmingham will award WIFIA Set #1 which includes (1) Grasselli Avenue SW / Doby Avenue SW (P.04207); (2) Brenda Avenue SW / Alvin Avenue SW (P.04391); and (3) Hillandale Drive / Rutledge Way (Fairfield) (P.04421) to a “single” Bidder based upon the total cost of the three (3) individual main replacement projects.

The Work consists of, but is not limited to the installation of approximately 3,310’ of 6” DICL “Zinc Coated” pipe; 3,090’ of 4” DICL “Zinc Coated” pipe; and 100 water services and other miscellaneous associated items as necessary to complete the Work along George Avenue Southwest; 39th Street Southwest; Howard Avenue Southwest; Grasselli Avenue Southwest; Todd Avenue Southwest; Felix Avenue Southwest; Doby Avenue Southwest; Spaulding Street Southwest; and Eli Avenue Southwest, located in the City of Birmingham, Alabama.

Bids shall be based on unit price items and lump sum items as indicated on the Bid Form (Section 00410).

Bidding Documents may be examined at the office of the Manager – System Development Department, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.

Bidders may obtain one (1) complete set of Bidding Documents from the office of the Manager -System Development Department, The Water Works Board of the City of Birmingham.  Partial sets of Bidding Documents will not be available to any Bidder.  Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources.  No Bidder may withdraw or alter his bid within ninety (90) calendar days after the actual date of the Bid Opening.

A Mandatory Pre-Bid Conference will be held at 10:00 a.m. local time on Tuesday, November 19, 2024, in person in the Meter Department Conference Room, 1st Floor Main Office Building (3600 1st Avenue North).  All Prospective Bidders are required to attend the Pre-Bid Conference. The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points.  Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference via conference call.  HUB Program Acknowledgement (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Resource Engagement Form (HUB Form 3), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.

Each Prospective Bidder is required to visit the site(s) at which the Work is to be performed.  The OWNER will not conduct a site visit with the Prospective Bidders.

Each Bid shall be accompanied by a certified check or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in Section 00435, Bid Bond.

The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.

Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders.  Bids will only be received from CONTRACTORS who are licensed by the State of Alabama.

Contract time of commencement and completion will be in accordance with the Agreement.

The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects.  To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on social or economic status.  Historically Underutilized Business (HUB): a business formed for the purpose of making a profit and is at least 51% owned, operated and/or controlled by one or more American citizens or permanent resident aliens who are a: Minority Business Enterprise (MBE); Women Business Enterprise (WBE); or Disadvantaged Business Enterprise (DBE) [herein sometimes collectively referred to as a HUB].

It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.

Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.

Alabama Code §31-13-9 (1975) provides that as a condition for the award of any Contract by The Water Works Board of the City of Birmingham (“BWWB”), a business entity or employer that employs one or more employees within the State of Alabama shall provide documentation of enrollment in the E-Verify program.

Each Prospective Bidder must complete Section 00200a Certification Regarding Debarment.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200b Certification Regarding Lobbying Restrictions.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200c Certification Regarding Civil Rights Obligations.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200d Certification Regarding EEO Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200e Certification Regarding AIS Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must complete Section 00200f Certification Regarding Telecon and Video Requirements.  The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).

Each Prospective Bidder must comply with Section 00452 Non-Discrimination Policy, while conducting business or participating in events or activities for the OWNER.  Each Prospective Bidder shall maintain an environment free of discrimination, harassment, and retaliation at all times.

Each Prospective Bidder must read, understand, and adhere to the requirements of Section 00740 Wage Determination Schedule relative to the minimum prevailing wage rates mandated by the applicable state labor department or other authority having jurisdiction (NO EXCEPTIONS).  Each Prospective Bidder is required to make sure his or her Subcontractor(s) understand the minimum prevailing wage rates for the work location.

Each Prospective Bidder must read and provide documentation relative to the “Request for Company Product and Service Information Letter” and complete the “EEO Report Form” document for the corporation, partnership, joint venture, etc. submitting a bid included at the end of the Section 00200 Instruction to Bidders.  These two (2) items must be included with the Prospective Bidder’s Bid.

Each Prospective Bidder shall read and understand the Alabama Department of Revenue’s (ADOR’s) sales and use tax exemption policy pursuant to Act 2013-205 Section 1(g)  [CONTRACTOR accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax – Attachment to BWWB Bid Form].  Failure to provide an accounting of sales tax shall render the Bid non-responsive.  Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder.  After Notice of Award, Prime Contractor and Subcontractor(s) licensed by the State Licensing Board for General Contractors must comply with ADOR reporting requirements for the duration of the project.  For further information see Section 00409, Alabama Department of Revenue-Sales and Use Tax Exemption, Section 00200 Instruction to Bidders (Article 33) and refer to paragraph 6.10 in the Supplementary Conditions.

If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the project and will result in the lowest overall cost to the OWNER for completion of the project.  Unless extended by OWNER, a Contract will be awarded within ninety (90) calendar days after the day of the opening of Bids.

The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.

Owner:
The Water Works Board of the City of Birmingham
3600 First Avenue North
Birmingham, Alabama 35222

Primary Contact:
Mr. Douglass W. Stockham, IV, P.E.
Telephone: (205) 244-4186
Facsimile: (205) 244-4686
E-mail: doug.stockham@bwwb.org

Secondary Contact:
Ms. Janice Acoff
Telephone: (205) 244-4265
Facsimile: (205) 244-4765
E-mail: janice.acoff@bwwb.org

Consultant Engineer:
A.G. Gaston Engineering LLC
1820 3rd Avenue North
Suite 400
Birmingham, Alabama 35203

Primary Contact:
Mr. Bo Linder, P.E.
Telephone: (205) 532-3853
E-mail: blinder@aggaston.com

BT11/14/2024

______________________________

IN THE SUPERIOR COURT OF DAWSON COUNTY
STATE OF GEORGIA

Civil Action
File No. 2024-AD-002-A

INRE:

ABIGAIL BINKLEY,
A minor child.
ARIANNA BINKLEY,
A minor child.

Petition of WANDA FAY FIELDS AND
JIMMY DON FIELDS.

NOTICE OF PUBLICATION

TO: CHRIS BINKLEY, FATHER OF THE ABOVE-NAMED CHILD

By order for service by publication dated the 22nd day of May 2024, you are hereby notified that on the 6th day of March 2024, Dee Anne Dial, Esq. filed a Petition for Adoption and Termination of Parental Rights as to A.B and A.B.

This matter has been set for final hearing on the 5th day of December, 2024 at 8:30 a.m., in the Superior Court of Dawson County, Dawson County Courthouse, Courtroom B.

WITNESS, the Honorable Amber Sowers, Judge of said Court, this the 28th day of October, 2024.

Justin Power, Clerk
Dawson County Superior Court
Dawson County, Georgia

BT11/14/2024

______________________________

ADVERTISEMENT FOR BIDS

Sealed proposals will be received by Birmingham City Schools at the office of Edward McMullen, Purchasing Department, 2015 Park Place North, Birmingham, Alabama 35203 until 10:00 a.m. local time Thursday, November 21, 2024 for the LED Video Scoreboard for Carver High School for Birmingham Board of Education, at which time and place they will be publicly opened and read.

A non-mandatory pre-bid conference and site visit is scheduled for 10:00 a.m., Wednesday, November 6, 2024 at: Carver High School, 3900 – 24th. Street, North, Birmingham, Alabama 35207.

Birmingham Board of Education has adopted a policy designed to encourage the participation of MBE/DBE firms in construction projects.

A cashier’s check or bid bond payable to Birmingham City Schools in an amount not less than five (5%) percent of the amount of the bid, but in no event more than $10,000.00, must accompany the bidder’s proposal.  Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.

Bid documents may be obtained and are available on the Districts website at https://www.bhamcityschools.org/page/332.

Bids must be submitted on proposal forms furnished by Birmingham Board of Education Purchasing Department or copies thereof.  All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975, and must show evidence of license before bidding or bid will not be received or considered by the Birmingham Board of Education: the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered.  The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interest of the Owner will thereby be promoted.

Owner:
Birmingham City Schools
2015 Park Place, North
Birmingham, Alabama    35203
Attn: Edward McMullen
purchasing@bhm.k12.al.us

BT11/14/2024

______________________________

ADVERTISEMENT FOR BIDS

Sealed proposals will be received by Birmingham City Schools at the office of Edward McMullen, Purchasing Department, 2015 Park Place North, Birmingham, Alabama 35203 until 10:30 a.m. local time Thursday, November 21, 2024 for the LED Video Scoreboard for Jackson-Olin High School for Birmingham Board of Education, at which time and place they will be publicly opened and read.

A non-mandatory pre-bid conference and site visit is scheduled for 11:00 a.m., Wednesday, November 6, 2024 at: Jackson-Olin High School, 1300 Avenue F, Ensley, Birmingham, Alabama 35218.

Birmingham Board of Education has adopted a policy designed to encourage the participation of MBE/DBE firms in construction projects.

A cashier’s check or bid bond payable to Birmingham City Schools in an amount not less than five (5%) percent of the amount of the bid, but in no event more than $10,000.00, must accompany the bidder’s proposal.  Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.

Bid documents may be obtained and are available on the Districts website at https://www.bhamcityschools.org/page/332.

Bids must be submitted on proposal forms furnished by Birmingham Board of Education Purchasing Department or copies thereof.  All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975, and must show evidence of license before bidding or bid will not be received or considered by the Birmingham Board of Education: the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered.  The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interest of the Owner will thereby be promoted.

Owner:
Birmingham City Schools
2015 Park Place, North
Birmingham, Alabama  35203
Attn: Edward McMullen
purchasing@bhm.k12.al.us

BT11/14/2024

______________________________

ADVERTISEMENT FOR BIDS

Sealed proposals will be received by Birmingham City Schools at the office of Edward McMullen, Purchasing Department, 2015 Park Place North, Birmingham, Alabama 35203 until 11:00 a.m. local time Thursday, November 21, 2024 for the LED Video Scoreboard for Wenonah High School for Birmingham Board of Education, at which time and place they will be publicly opened and read.

A non-mandatory pre-bid conference and site visit is scheduled for 1:00 p.m., Wednesday, November 6, 2024 at: Wenonah High School, 2800 Wilson Road, SW, Birmingham, Alabama 35221.

Birmingham Board of Education has adopted a policy designed to encourage the participation of MBE/DBE firms in construction projects.

A cashier’s check or bid bond payable to Birmingham City Schools in an amount not less than five (5%) percent of the amount of the bid, but in no event more than $10,000.00, must accompany the bidder’s proposal.  Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.

Bid documents may be obtained and are available on the Districts website at https://www.bhamcityschools.org/page/332.

Bids must be submitted on proposal forms furnished by Birmingham Board of Education Purchasing Department or copies thereof.  All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975, and must show evidence of license before bidding or bid will not be received or considered by the Birmingham Board of Education: the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interest of the Owner will thereby be promoted.

Owner:
Birmingham City Schools
2015 Park Place, North
Birmingham, Alabama 35203
Attn: Edward McMullen
purchasing@bhm.k12.al.us

BT11/14/2024

______________________________

ADVERTISEMENT FOR A/V FIRM REQUEST FOR STATEMENT OF QUALIFICATIONS

DATE: November 7, 2024
FROM: Jefferson County Commission
General Services Department, Room 1
716 Richard Arrington Jr. Blvd. North
Birmingham, Alabama 35203

RE: REQUEST FOR QUALIFICATIONS

The General Services department on behalf of the Jefferson County Commission is conducting the A/V Firm services selection process for the described Project.

PROJECT TITLE: Jefferson County Coroner/Medical Examiner Office Audio Visual System Design
PROJECT LOCATION:  100 Leaf Lake Blvd, Birmingham, Alabama 35211
PROJECT ESTIMATED CONSTRUCTION BUDGET: TBD

DEADLINE FOR SUBMISSIONS:  December 5, 2024, 2:00 P.M.

This project involves turnkey professional services for the design and implementation of Audio-Visual (A/V) solutions at the Jefferson County Coroner/Medical Examiner Office. The scope includes A/V systems for a training room, conference room, and five office CCTV monitors, covering design, bid preparation, bid assistance, and installation management.

General requirements:  The A/V Firm shall be responsible for the professional quality, technical accuracy, and coordination of the design work.  The A/V Firm will coordinate with the Architect and Contractor on the design and installation of the A/V systems.

The A/V Firm shall coordinate with the appropriate public utility companies and commissions, if required, to prepare connection designs according to the applicable guidelines. Submissions shall be prepared (and revised and resubmitted, if necessary) for securing approvals, class of service, permits, and service hook-ups.

The work shall comply with all applicable City of Birmingham, Jefferson County, State of Alabama, federal codes and regulations.  The work shall also comply with any applicable utility provider, construction industry and ASHRAE standards, requirements, and guidelines.

The work shall conform with the “to be established” project budget and scope, once finalized, throughout planning, design, and installation.

The AV Firm shall make site visits, attend meetings, produce meeting minutes, make presentations, and submit required deliverables as necessary to execute specific parts of the work ‘to be established’ and in the Contract and the Scope of Work for the project. The A/V Firm will be available to perform optional installation phase services at the agreed upon rate, if requested by the Jefferson County Commission.

If you would like to be considered for this Project, please provide one (1) complete copy of your documentation to our office by the deadline indicated above.  Minority, women and disabled veteran-owned enterprises (DBE) are encouraged to apply. Significant local participation is recommended for services for firms outside the State of Alabama. All qualification submissions shall be made in hard copy, bound 8 1/2 x 11 format.  Electronic files may be submitted in addition to hard copy.  Electronic submissions are to be in PDF format transmitted via a USB drive delivered to our office by the deadline indicated above. Electronic files are not required but are preferred.

Please include the following items in your packet:

Identify each specific qualification request identifiable by associated item numbers and tabbed accordingly below:

Qualification Package

1. Approach. A general statement of the firm’s approach with particular focus on distinguishing characteristics or services.

2. Work proposed to be performed. A discussion of the firm’s understanding of the scope of services to be provided and the major work tasks to be performed.

3. Key personnel. A list of the proposed project team assigned to this project and their roles, previous related experience, education, and date that person joined the firm.

4. Relevant experience. A statement of the firm’s relevant experience, including a brief description of projects similar in scope and size as the proposed project, include project title, dates work was performed, construction value, and client contact information.

5. Certificate of Insurance. Submit a copy of the firm’s certificate of insurance.

6. Include statement of DBE status. Is your firm a “Disadvantaged Business Enterprise”; Minority, women or disabled veteran-owned enterprise? Include statement of DBE status for each identified sub consultant/engineer listed for each package if applicable.

All questions regarding this project and submittal of the Statement of Qualifications shall be directed to Andy Olds, Committee Chair at email address andy.olds@jccal.org. Any contact with the selection committee team members other than Mr. Olds or his designee may disqualify the firm’s proposal from consideration.

BT11/14/2024

______________________________

NOTICE TO CONTRACTORS

The City of Birmingham gives notice that sealed bids for 25th Street North Improvements (The Star Development Infrastructure Work) at Carraway Phase 1 will be received by the City Engineer in Room 220, City Hall, Birmingham Alabama until 2 o’clock p.m. (CDT), December 18, 2024 at which time and place they will be publicly opened and read in Conference Room 220, 2nd Floor City Hall, Birmingham, Alabama. The award of this Contract will be made pursuant to Alabama Code: 39-1-1, et seq. (Public Works)

All bidders must have a UEI (Unique Employee Identification) number issued by the U.S. General Services Administration to be eligible to bid on ARPA funded project. UEI numbers can be obtained by signing up at http://sam.gov. Registration is not required to obtain a UEI number.

All bidders are required to submit a Debarment form completed by a company principal and included inside the sealed bid envelope. The bidders UEI number must be provided on the Debarment form.

The Principal Items of Work related to this project are below (refer to bid documents for the complete list):

Item No.          Estimated Quantity        Unit            Description
1                                    1                        LS              Mobilization

2                                    1                        LS              Site Layout and Staking for Sitework

3                                    1                        LS              Traffic Control

4                                    1                        LS              Certified As-builts (Storm)

5                                    1                        LS              Dust Control/Temporary Stabilization

6                                    1                        EA              Demobilization

7                                    1.0                    LS              Clearing and Grubbing

8                                    1                        LS              Misc. Demo

9                                    1710                  LF              Demo curb and gutter

10                                  59863                SF              Existing Asphalt Paving (Including
Cobblestone/Pavers beneath)(less Milling)

11                                   6978                SF               Demo Existing Sidewalk

12                                   5910                SF              Demo Existing Concrete Drives

13                                        47                LF              Demo 12″ Clay Pipe

14                                        51                LF              Demo 15″ Clay Pipe

15                                          1                EA              Demo existing inlet

16                                          1                EA              Demo Existing Manhole

17                                          4                EA              Relocate existing Hydrant

18                                        260              LF            Remove existing fence

19                                          23              EA            Remove and replace existing signs

20                                            5               LF            Demo existing wall

21                                            1               LS            Adjust existing manhole tops/inlets/valves/etc to
match final paving

22                                            5              EA            Abandon Chilled Water Manholes

23 8 EA Tree Protection

24 4228 LF Type A Silt Fence

25 25 EA Inlet Protection

26 1172 LF Straw Wattles

27 1 EA Concrete Washout

28 0.24 AC Permanent Seeding and Mulching

29 1 EA Construction Entrance / Exit

30 4228 LF Remove Silt Fence

31 1172 LF Remove Straw Wattle

32 25 EA Remove Inlet Protection

33 2129 SY Erosion Control Blanket

34 1508 CY Double handle / Waste Excess topsoil Off-Site

35 824 CY General Site Grading / Cut to Fill

36 13369 SY Total Fine Grading

37 5 EA Type S Single Wing Curb Inlet

38 461 LF 18″ RCP CLIII, Including stone backfill

39 2 EA Storm Sewer Manholes

40 5 EA Tie to Existing Storm Sewer

41 1554 LF ALDOT Type C Curb and Gutter

42 1 EA Type N Safety Gore Nose

43 227 LF 24″ Valley Gutter

44 125 SY Mill 1.5″ and Overlay Asphalt

45 6763 SY Asphalt wearing surface

46 6640 SY Bituminous Asphalt Binder

47 1550 Tons Crushed Aggregate Base

48 1587 Gal Prime Coat

49 337 Gal Tack Coat

50 6 EA Painted White Crosswalk

51 7 EA Painted White Stop Bar

52 4200 LF Painted White 5″ wide striping W/ 17″ Space @ 45°

53 880 LF Painted Yellow Striped Loading Zone

54 1080 LF Painted Double Yellow Stripe

55 221 LF Painted White Parking Stalls

56 7735 SF Green Bike Lane Surfacing

57 16 EA Painted white Bike Lane Markings

58 5 EA Signage

59 13265 SF Concrete Sidewalks

60 10 SF Dense Graded Base for Sidewalks

61 2972 EA Accessible Ramps at Intersections

62 4 LF Conduit only for Pole to Pole (2ea – 3″ Conduit)

63 1 LF 2″ Type K Copper Irrigation Service

64 1EA 2″ RPZ with hotbox and slab heater

65 7 LS Irrigation materials

66 21 EA Street Light Type 1

67 28 EA Street Light Type 2

68 9 EA Autumn Fire American Hornbeam

69 7 EA Carolina #2 American Holly

70 11 EA Princeton American Elm

71 621 EA Winter King Hawthorn

72 725 QT Guara Full Plant

73 725 QT Bee Balm Full Plant

74 955 QT Black-Eyed Susan Full Plant

75 3280 SY Bermuda Grass

76 3280 LF
Temporary Perimeter Fencing During Construction

Bid documents are open to public inspection in the Office of the City Engineer, Room 220 City Hall, 710 20th Street, North Birmingham, AL 35203.

Bid documents may be viewed and purchased through the City of Birmingham online plans room site at https://www.birminghamplanroom.com under the project name “25th Street North Improvements (The Star Development Infrastructure Work) at Carraway Phase 1”. Any cost for reproduction shall be the responsibility of bidders.

Prospective bidders are advised to check their source of bid documents frequently for any addenda to the bid documents. It is the bidder’s responsibility to bid on the correct set of bid documents.

Bids shall be accompanied by a cashier’s check drawn on an Alabama bank, or a bid bond executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama, in an amount equal to 5% of the bid (subject to a maximum of $10,000) and payable to the City of Birmingham. Bid bonds of the three (3) lowest bidders will be held for a period of ninety (90) days unless bidders agree, in writing, to a longer period of time.  No bid may be withdrawn after the scheduled closing time for receipt of bids and for a period of ninety (90) days thereafter.

A performance bond equal to 100% of the contract amount and a payment bond equal to 100% of the contract amount will be required of the successful bidder. Said bonds shall be executed by a surety company duly authorized and qualified to make such bonds in the State of Alabama.

Liability insurance certificates shall be required of the successful bidder and such certificates shall list the City of Birmingham, its officials, agents, and employees as additional named insured.

Only bids submitted by General Contractors licensed in the State of Alabama in accordance with Title 34, Chapter 8 of the Code of Alabama (1975 as amended) will be considered.

Bids shall be submitted in a sealed envelope marked “SEALED BID – 25th Street North Improvements (The Star Development Infrastructure Work) at Carraway Phase 1”. Contractors shall write on the outside of the sealed bid envelope his or her State of Alabama general contractor’s license number as well as the name of the company submitting the bid.

The sealed bid envelope shall contain the following documents in the order listed below and labeled: (1) the Form of Proposal, (2) the Authorization to execute the Form of Proposal, (3) bid bond, (4) MBE/DBE Form A, Form C and Form D, (5) a copy of the Contractor’s State of Alabama General Contractor’s License, (6) the Contractor’s Completed Debarment Form, (7) and Addendum Acknowledgement.

Special attention is called to the applicability of the Birmingham Plan-Construction Industry Program to this project.  Under this Program the utilization of Minority Business Enterprises and Disadvantaged Business Enterprises (“MBE/DBE”) is encouraged.  The Construction Industry Authority establishes a system of floating MBE/DBE goals which may differ from year to year and project to project.  Overall, these goals shall not be less than the historical participation of MBE/DBE’s in construction projects of the City and its agencies.

Bidders may contact the Birmingham Construction Industry Authority (BCIA) to request additional information about the required MBE/DBE forms by contacting the Executive Director, Birmingham Construction Industry Authority at 601 37th Street South, Birmingham, AL, 35222; telephone (205) 324-6202 or info@bcia1.org.  For federally funded contracts, the provisions of the President’s Executive Order 11246 and federal agency regulations requiring affirmative action to achieve employment and utilization of minority persons and businesses, and the Davis-Bacon Act provisions are applicable.

As a matter of public policy, the City of Birmingham agrees to make opportunities available to the maximum extent possible, to actively include Historically Underutilized Business Enterprises (HUBE’s) such as architectural firms, engineering firms, investment banking firms, other professional consultant services providers, and construction contractors as part of business, economic and community revitalization programs.

It is the bidder’s responsibility to make sure that his bid is in the possession of the City Engineer on or before 2:00 p.m., December 18, 2024.  Bids received after this time will not be considered. Bids can be dropped into the Bid Box located in Room 220 City Hall, delivered to the City Engineer in Room 220 City Hall.

A MANDATORY PRE-BID CONFERENCE will be held on Wednesday, December 4, 2024, at 10:00 am (CST) in Conference Room 220 City Hall.

The City of Birmingham reserves the right to reject any or all bids and to waive any informality in any bid.

Jesse P. Miller, PE
City Engineer

BT11/14/2024

______________________________

REQUEST FOR PROPOSALS

The Birmingham Airport Authority (“BAA” or “Authority”) is requesting proposals (RFP) from highly experienced and professional firms to Design and Upgrade LAN Infrastructure and Wi-Fi Systems at the Birmingham Shuttlesworth International Airport. The goal of this procurement effort is to enter into a contract with the best-valued Contractor for Design and Upgrade LAN Infrastructure and Wi-Fi Systems at BHM. Copies of the RFP can be obtained by visiting the Airports Website at http://www.flybhm.com or via email request sent to eseoane@flybhm.com.

BT11/14/2024

______________________________

NOTICE TO BIDDERS

Sealed Bid Proposals will be received by the Environmental Services Department, Jefferson County, Alabama, online at QuestCDN (eBidDoc #9400401), until 2:00 P.M. local time on Wednesday, December 18, 2024 and then publicly opened and read via virtual video conference using Microsoft Teams for the SANITARY SEWER SYSTEM – ASSET MANAGEMENT PROGRAM – CONTRACT NO. 2023 PS05 – ALEMEDA AND COLLEGEVILLE STATION IMPROVEMENTS PROJECT Microsoft Teams can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen and Sawyer, at tpowell@hazenandsawyer.com). The scope of work includes the rehabilitation and replacement of two pump stations in Jefferson County. The work is detailed on the Contract Plans and generally described for each station below:

Alemeda Pump Station (PS047):

• Demolition of existing can pump station including, but not limited to, pumps, piping, and electrical components;
• Installation of approximately 123 linear feet of 8-inch sanitary sewer pipe;
• Installation of approximately 60 linear feet of 10-inch sanitary sewer pipe;
• Installation of six 48-inch diameter precast concrete manholes;
• Installation of one 60-inch diameter precast concrete doghouse manhole with;
• Installation of 8-foot diameter precast concrete wet well with monolithic liner;
• Installation of 7-foot by 7-foot precast concrete valve vault;
• Installation of two submersible pumps with all piping, valves, fittings and appurtenances;
• Installation of pump station electrical components;
• Installation of natural-gas-powered backup generator;
• Removal, relocation, and installation of electrical riser poles, transformers, and overhead lines;
• Site improvements, including concrete paving, concrete pump station pad, retaining walls, curb and valley gutter replacement and restoration work.

Collegeville Pump Station (PS050):

• Demolition of existing pump station, including but not limited to, pumps, piping, building structure, and electrical components;
• Installation of 5-foot by 5-foot precast concrete bypass structure with two 24-inch slide gates and cast-in-place concrete base;
• Conversion of existing wet well and dry pit into auxiliary overflow storage structure;
• Installation of approximately 106 linear feet of 24-inch new sanitary sewer pipe;
• Installation of three new 60-inch diameter precast concrete manholes;
• Installation of one 19-foot by 19-foot cast-in-place concrete wet well with monolithic liner;
• Installation of three submersible pumps with all piping, valves, fittings and appurtenances;
• Installation of one 19-foot by 9-foot cast-in-place concrete valve vault;
• Installation of one 60-inch diameter precast concrete manhole with magnetic flow meter;
• Installation of one elevated generator building with exterior platform and natural-gas-powered backup generator and electrical equipment and pump station electrical components;
• Removal and installation of electrical riser poles, transformers, and overhead lines;
• Site improvements, including gates, fencing, concrete paving, concrete pump station pad, lighting, and restoration work.

Bidding Documents are on file for inspection, by appointment only, at the following location:

Jefferson County Environmental Services Department
716 Richard Arrington Jr. Boulevard North, Suite A-300
Birmingham, Alabama 35203
Contact for Appointment: Brian Rohling at (205) 521-7512

Complete sets of electronic Bidding Documents (Specifications and Drawings) are available at https://www.jccal.org/Default.asp?ID=2246&pg=Notice+To+Bidders (navigate to “Asset Management Program – Project Bid Information” for a listing of projects.) Prior to downloading the Bidding Documents, Bidders will be required to set up a QuestCDN.com account and pay a $42.00 fee. Hard copies of the Bidding Documents are the responsibility of the Bidders. Contact QuestCDN at 952-233-1632 or info@questcdn.com for assistance with navigating the website and digital project information.

Bids will only be accepted from pre-qualified contractors who are listed on the Plan Holders List, signifying that they have purchased a set of documents from the Engineer, and who attend the MANDATORY Pre-Bid Conference.

NO BID PROPOSAL SHALL BE ACCEPTED AFTER THE TIME STATED FOR RECEIVING BID PROPOSALS IN THIS NOTICE. A FORM CONTAINING THE CONTRACTOR’S NAME AND ADDRESS OF THE FIRM AND THE CONTRACTOR’S ALABAMA LICENSE NUMBER WITH THE DATE OF EXPIRATION IS REQUIRED WITH THE SUBMISSION OF THE BID. THESE REQUIREMENTS SHALL NOT BE WAIVED.

The Contractor is hereby advised that TIME IS OF THE ESSENCE on this project. The Contract Time for this project is six hundred and thirty-five day (635) consecutive calendar days. The first 270 days will be an administrative period followed by a 365-day construction period from the effective date of the written Notice to Proceed to achieve Final Acceptance. If mutually agreed upon between the Owner and Contractor, the construction period may commence prior to the end of the administrative period. Upon such agreement the contract end date will be modified based on the date of termination of the administrative period. Liquidated damages will be assessed if this time limit is exceeded. The Contractor may apply for an extension of time in accordance with the provisions of the Contract; however, such an extension must be approved prior to the Contract Completion Date to avoid the imposition of liquidated damages.

The Contractor is hereby advised that a Pre-Bid Conference will be held via a virtual video conference on Wednesday December 4, at 2:00 PM. This Pre-Bid Conference is MANDATORY for all contractors planning to submit a Bid Proposal on this project. The conference call will be held using Microsoft Teams and can be accessed using a direct invitation link sent via email (request this link from Tad Powell, Hazen and Sawyer, at email tpowell@hazenandsawyer.com). If you are unable to join the call due to technical difficulties, call Tad Powell (Hazen and Sawyer) at 205-957-4151 or Brian Rohling (Jefferson County) at 205-521-7512 for assistance.

Questions concerning meaning or intent of Bidding Documents shall be submitted to Tad Powell, PE, Senior Associate, Hazen and Sawyer, at email tpowell@hazenandsawyer.com no later than 5:00 p.m. local time on December 6, 2024. All questions must be in writing on Bidder’s company’s letterhead.

THE ATTENTION OF ALL BIDDERS IS CALLED TO THE PROVISIONS OF THE STATE LAW GOVERNING GENERAL CONTRACTORS, AS SET FORTH IN ALABAMA CODE SECTIONS 34-8-1 THROUGH SECTION 34-8-28 (1975), AS AMENDED, CHAPTER 4, SECTION 65 TO 82 (INCLUSIVE) OF TITLE 46 OF THE CODE OF ALABAMA OF 1940, AS AMENDED; AND BIDDERS SHALL BE GOVERNED BY SAID LAW INSOFAR AS IT IS APPLICABLE. THE ABOVE MENTIONED PROVISIONS OF THE CODE MAKE IT ILLEGAL FOR THE OWNER TO CONSIDER A BID PROPOSAL FROM ANYONE WHO IS NOT PROPERLY LICENSED UNDER SUCH CODE PROVISIONS.

THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-2-14 (1975) AS AMENDED, REQUIRING A NONRESIDENT CONTRACTOR TO REGISTER WITH THE DEPARTMENT OF REVENUE PRIOR TO ENGAGING IN THE PERFORMANCE OF A CONTRACT IN THE STATE OF ALABAMA.

THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA CODE SECTION 39-3-5 (1975) AS AMENDED, REGARDING PREFERENCE TO RESIDENT CONTRACTORS.

THE ATTENTION OF BIDDERS IS CALLED TO THE PROVISIONS OF ALABAMA ACT 2016-312 AS AMENDED, REGARDING NOT ENGAGING IN THE BOYCOTT OF A PERSON OR ENTITY BASED IN OR DOING BUSINESS WITH A JURISDICTION WITH WHICH THIS STATE ENJOYS OPEN TRADE.

THIS PROJECT IS CLASSIFIED AS A CLASS ”D” (PUMP STATION AND PACKAGE PLANT FACILITY) SEWER PROJECT. ALL PROSPECTIVE BIDDERS MUST BE PRE-QUALIFIED WITH THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT TO BID CLASS “D” PUMP STATION AND PACKAGE PLANT PROJECTS IN ORDER TO BID ON THIS PROJECT. To pre-qualify with the department to construct class “D” PUMP STATION AND SEWER LINE PROJECTS, each prospective bidder must furnish written evidence of competency and evidence of financial responsibility to the county.

ACCORDINGLY, THE COUNTY WILL NOT ACCEPT PRE-QUALIFICATIONS AFTER 5:00PM LOCAL TIME ON Friday November 29, 2024. BID PROPOSAL FORMS WILL NOT BE ISSUED TO PROSPECTIVE BIDDERS WHO DO NOT PRE-QUALIFY.

CONTRACTORS ARE ENCOURAGED TO CONTACT THE JEFFERSON COUNTY ENVIRONMENTAL SERVICES DEPARTMENT, 716 RICHARD ARRINGTON JR. BOULEVARD NORTH, SUITE A300, BIRMINGHAM, ALABAMA, (205) 325-5496 IN ADVANCE OF THE DEADLINE TO DETERMINE IF THE CONTRACTOR IS PRE-QUALIFIED TO CONSTRUCT CLASS “D” SEWER PROJECTS, OR FOR OTHER INFORMATION REGARDING THE REQUIREMENTS FOR PRE-QUALIFICATION.

BY:
David Denard
Director of Environmental Services
Jefferson County, Alabama

BT11/14/2024

______________________________

NOTICE TO BIDDERS

The Birmingham Water Works Board will be accepting bids for BID24-04-10 “Pipe and Fittings (Annual)”. The specifications and conditions may be examined and obtained in the Purchasing Department’s office at 3600 First Avenue North, Birmingham, AL 35222, or by calling LyTonja Levert @ 205-244-4305, or emailing tonja.levert@bwwb.org, and on our web-site @ www.bwwb.org.

Sealed bids for Pipe and Fittings (Annual) will be received in the Purchasing Department no later than 10:00 a.m., Thursday, November 21, 2024, at which time and place they opened and read.

You can mail your bid to 3600 1st Avenue North, Birmingham, Alabama 35222, directed to the attention of LyTonja Levert, Interim Purchasing Manager and marked in the lower left-hand corner of the envelope as follows: “Pipe and Fittings (Annual)” – due 10:00 a.m., Thursday November 21, 2024.”

BT11/14/2024

______________________________

ADVERTISEMENT for BIDDER PRE-QUALIFICATION
And NOTICE of INTENT to RECEIVE BIDS
from PREQUALIFIED BIDDERS

Pre-qualification submittals will be received by the Owner’s Representative/Project Manager, Chris Hodges on behalf of Office of the Chief Facilities Officer, UAB Medicine, University of Alabama at Birmingham, and the University of Alabama Board of Trustees at UAB Hospital Planning, 2020 University Blvd., Birmingham, AL 35249 until 4:00 PM Central Time, December 6, 2024.  The original and two (2) flash drives with duplicates of submittals are required for pre-qualification approval; however, email transmission copies may be transmitted to the UAB Project Manager Chris Hodges at cjhodges@uabmc.edu and cc’d to sheywood@ghafari.com and mfreeman@ghafari.com to expedite the review process with a hard-copy of the submittal and two flash drives to be delivered within 24 hours.

UAB Marriott PIP 2024
University of Alabama at Birmingham
Birmingham, Alabama
Project No.: H245021

A. SCOPE OF WORK:

The project consists of the replacement of bathroom vanity mirrors and associated lights in all hotel guestrooms of the existing UAB Marriott Hotel.  The scope of work includes minimal architectural, electrical, and demolition work. The work will be performed by a single Prime General Contractor who has experience managing and coordinating work of similar size and scope as a General Contractor (not as a Construction Manager, Program Manager, etc…). The anticipated construction budget is between $400,000 and $500,000.

B. PRIME GENERAL CONTRACTOR BIDDER PRE-QUALIFICATIONS:

Prime General Contractor bidders interested in submitting a proposal must apply for pre-qualification and must be licensed under the Provision of Title 34, Chapter 8, and Code of Alabama, 1975. A copy of current Alabama Contractors license is to be included in pre-qualification submittal.

Only bidders who have completed the pre-qualification process and that have been approved will be eligible to submit a bid for the Project.  Prospective Bidder’s Pre-qualification Package must be received by the Owner’s Project Manager no later than 4:00 PM Central Time, December 6, 2024 after which no further requests will be considered.

Pre-qualification Requirements Information Package may be obtained from the Architect upon letterhead request sent by email or scanned into an email to sheywood@ghafari.com, copy mfreeman@ghafari.com and cjhodges@uabmc.edu. Any addenda to the prequalification requirements will be issued to documented prime contractors only.

The pre-qualification procedure is intended to identify responsible and competent prime contractor bidders relative to the requirements of the Project.  Each prospective prime contractor bidder will be notified of the results of the pre-qualification, on or about December 9, 2024.

The Owner reserves the right to waive technical errors in applications, extend or abandon the pre-qualification process, should the interests of the Owner appear to be promoted thereby.

Progress Design and Construction Documents:
Prior to the pre-qualification deadline, project progress plans and specifications may be examined at the following location beginning December 9, 2024:

Architect:
Ghafari Associates
2170 Highland Ave S
Suite 220
Birmingham, AL 35205
Phone:  205-203-4611
Contact: Scott Heywood
Email: sheywood@ghafari.com

C. BIDS BY PRE-QUALIFIED PRIME GENERAL CONTRACTOR BIDDERS

Documents:
Bid documents will be available at the following locations after notice to pre-qualified bidders is given.  Drawings and specifications may be examined at; ALGX Digital Plan Room, http://www.algraphics.com, 2801 5th Ave, South, Birmingham, AL 35233: Dodge Data & Analytics, http://www.construction.com, 2860 S State Hwy 161, Ste 160 #501, Grand Prairie, TX  75052-7361; at the AGC Internet Plan Room, 5000 Grantswood Road Suite 100, Irondale, AL 35210; at the Birmingham Construction Industry Authority, http://www.bcia1.org, 601 37th Street South, Birmingham, AL 35222; and at the Construction Market Data, http://www.cmdgroup.com, 30 Technology Pkwy, South, Suite 500, Norcross, GA 30092-2912.

Bonds:
A certified check or bid bond payable to the University of Alabama at Birmingham in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000 must accompany the bidder’s proposal.  Performance and Statutory Labor and Material Payment Bonds will be required at the signing of the Contract.

Bids:
Bids must be submitted on proposal forms or copies thereof furnished by the Architect. No bid may be withdrawn after the scheduled closing time for receipt of bids for a period of ninety (90) days. The Owner reserves the right to reject bids if such action is determined to be in the best interest of the Owner. The Owner reserves the right to revoke pre-qualification of any bidder in accordance with Section 39-2-12, Code of Alabama, 1975, as amended in 1997 (by Act 97-225). The Bid Date is December 19, 2024 at 2:00 PM Central Time at the University of Alabama at Birmingham, UAB Hospital Planning, 2020 University Blvd., Birmingham, Alabama 35294. Bids shall be clearly identified on the exterior of the package with the bidder’s name, address, State license number, the name of the project being bid, time and place of the bid opening. Sealed bids shall be properly identified.

On the date of the bid opening, bids may be hand delivered or received by Express Service mail to the Office of Chris Hodges, Project Manager Facilities and Capital Projects, 2020 Building, 2020 University Blvd, Birmingham, Alabama  35233, until 12:00 noon.  After 12:00 noon of the date of the bid opening, proposals must be hand delivered and presented at the bid opening.  Sealed proposals shall be submitted in triplicate and shall be properly identified.  All proposals received after 2:00 p.m. on December 19, 2024 (the date and time set for the receipt of bids) will be returned unopened.

Nonresident Prime Contractor Bidders:
Under Section 39-3-5, Code of Alabama, 1975, nonresident prime contractor bidders must accompany any written bid documents with a written opinion of an attorney licensed to practice law in such nonresident prime contractor bidder’s state of domicile as to the preferences, if any or none, granted by the law of the state to its own business entities whose principal place of business are in that state in the letting of any or all public contracts.  Resident prime contractors in Alabama, as defined in Section 39-2-12, are granted preference over nonresident prime contractors in awarding of contracts in the same manner and to the same extent as provided by the laws of the state of domicile of the nonresident.

Fire Alarm Work:
In accordance with Title 34, Chapter 33A (the ACT), of the Code of Alabama 1975, bidders for fire alarm work of this project, if any, must include with their bid evidence of licensure as required by the ACT by including with the bid submittal a valid State Fire Marshal’s permit.

D. PRE-BID CONFERENCE

A mandatory Pre-Bid Conference is currently scheduled to be held at 1:00 PM CST on December 11, 2024 at UAB Hospital Facilities 2020 Building, 2020 University Blvd., Birmingham, Alabama 35233. It is mandatory that all pre-qualified prime contractor bidders attend the Pre-Bid Conference.

BT11/14/2024

______________________________

ADVERTISEMENT for BIDDER PRE-QUALIFICATION
And NOTICE of INTENT to RECEIVE BIDS
from PREQUALIFIED BIDDERS

Pre-qualification submittals will be received by the Owner’s Representative/Project Manager,
David McCabe on behalf of Office of the Chief Facilities Officer, UAB Medicine, University of Alabama at Birmingham, and the University of Alabama Board of Trustees at UAB Hospital Planning, 2020 University Blvd., Birmingham, AL 35249 until 4:00 PM Central Time,
Friday, December 6, 2024.  The original and two (2) flash drives with duplicates of submittals are required for pre-qualification approval; however, email transmission copies may be transmitted to the Project Manager at dcmccabe@uabmc.edu and copied to rachelh@bparchitects.com to expedite the review process with a hard-copy of the submittal and two flash drives to be delivered within 24 hours.

UAB HOSPITAL – NP 6th Floor – Demolition of Administrative Area
For The
University of Alabama at Birmingham
Birmingham, Alabama
UAB Project No.:  H245017

A. SCOPE OF WORK:

The project consists of demolition of approximately 2,250 SF Administration Area.  The project will be broken into multiple phases. The scope of work includes, but is not limited to ceilings, finishes, plumbing, electrical work, and equipment coordination. The demolition budget is anticipated to be between $110,000-$175,000.

The work will be performed under a single Prime General Contractor who will coordinate the work of this project. Particular and specific care will be required to coordinate complex shutdowns, limit disturbances and follow strict Infection Control and Interim Life Safety Measures (ICRA/ILSM) requirements for the protection of patients, family, and staff. The Prime General Contractors seeking to be pre-qualified will require experience with similar size and type hospital projects performed in and adjacent to an operating hospital environment and with the implementation and maintenance of infection control measures, interim life safety measures, coordinating shutdowns, and maintaining a clean and organized job site in an operating hospital. The General Contractor must have experience with representative projects as a General Contractor (not as a Construction Manager, Program Manager, etc.)

B. PRIME CONTRACTOR BIDDER PRE-QUALIFICATIONS:

Prime contractor bidders interested in submitting a proposal must apply for pre-qualification and must be licensed under the Provision of Title 34, Chapter 8, and Code of Alabama, 1975. A copy of current Alabama Contractors license is to be included in pre-qualification submittal.

Only prime contractor bidders who have completed the pre-qualification process and that have been approved will be eligible to submit a bid/perform work for the Project.  Prospective Bidder’s Pre-qualification Package must be received by the Owner’s Project Manager no later than 4:00 PM Central Time, December 6, 2024 after which no further requests will be considered.

Pre-qualification Requirements Information Package may be obtained from the Architect upon letterhead request. Any addendums to the prequalification requirements will be issued to documented prime contractors only.

The pre-qualification procedure is intended to identify responsible and competent prime contractor bidders relative to the requirements of the Project.  Each prospective prime contractor bidder will be notified of the results of the pre-qualification, on or about
December 13, 2024.

The Owner reserves the right to waive technical errors in applications, extend or abandon the pre-qualification process, should the interests of the Owner appear to be promoted thereby.

Progress Design and Construction Documents:

Prior to the pre-qualification deadline, project progress plans and specifications may be examined at the following location:

Architect:
Birchfield Penuel Architects
2805 Crescent Avenue, Suite 200
Birmingham, Alabama  35209
Ms. Alicia Pughsley
205-870-1876
aliciap@bparchitects.com

C. BIDS BY PRE-QUALIFIED PRIME GENERAL CONTRACTOR BIDDERS

Documents:
After notice to pre-qualified bidders is given, the pre-qualified prime contractor bidders may obtain bid documents from the Architect (see address above) upon deposit of $100.00 per set.  The deposit is refundable in full on the first two (2) sets issued to each prime general contractor bidder upon return of documents in reusable condition within ten (10) days after bid opening.  Additional sets for pre-qualified prime contractor bidders, subcontractors, vendors, or dealers may be obtained upon payment of the same deposit.  The deposit for additional sets shall be refunded less the cost of printing, reproduction, handling and distribution, upon return of the documents in reusable condition within ten (10) days after bid opening.

Bid documents will be available at the following locations after notice to pre-qualified bidders is given.  Drawings and specifications may be examined at the Office of the Architect; and electronically at ConstructConnect and Dodge Data & Analytics.

Bonds:
A certified check or bid bond payable to the University of Alabama at Birmingham in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000 must accompany the bidder’s proposal.  Performance and Statutory Labor and Material Payment Bonds will be required at the signing of the Contract.

Bids:
Bids must be submitted on proposal forms or copies thereof furnished by the Architect. No bid may be withdrawn after the scheduled closing time for receipt of bids for a period of ninety (90) days.  The Owner reserves the right to reject bids if such action is determined to be in the best interest of the Owner.  The Owner reserves the right to revoke pre-qualification of any bidder in accordance with Section 39-2-12, Code of Alabama, 1975, as amended in 1997 (by Act 97-225). The Bid Date is January 9, 2025 at 2:00 PM Central Time at the University of Alabama at Birmingham, UAB Hospital Planning, 2020 University Blvd., Birmingham, Alabama 35294. Bids shall be clearly identified on the exterior of the package with the bidder’s name, address, State license number, the name of the project being bid, time and place of the bid opening. Sealed bids shall be properly identified.

Proposals may be hand delivered or received by mail on the date of the bid opening at the Office of David McCabe, Project Manager Facilities and Capital Projects, 2020 Building, 2020 University Blvd, Birmingham, Alabama 35233, until 12:00 noon.  After 12:00 noon of the date of the bid opening, proposals must be hand delivered and presented at the bid opening.  Sealed proposals shall be submitted in triplicate and shall be properly identified. All proposals received after 2:00 p.m. on
January 9, 2025 will be returned unopened.

Fire Alarm Work
In accordance with Title 34, Chapter 33A, of the Code of Alabama 1975, bidders for fire alarm work of this project, if any, must include with their bid, evidence of licensure as required by the act, by including with the bid submittal, a valid State Fire Marshal’s permit.

D. PRE-BID CONFERENCE
A mandatory Pre-Bid Conference will be held Wednesday, December 18, 2024 at 10:00 am at UAB Hospital Facilities, 2020 University Blvd., Birmingham, Alabama 35233. It is mandatory that all pre-qualified prime contractor bidders attend the Pre-Bid Conference.

BT11/14/2024

_________________________

*********************************************************
( Please make sure there is Bold line around ad )
*********************************************************

ATTENTION

In search of individuals who were employed at
Ed Mollison Chevrolet in Birmingham, AL between
1954-1980 and worked with or knew DOUGLAS
HENLEY, please call 1-855-988-2537.

BT11/14/2024

____________________________

VEHICLE AUCTION

Vehicle Information:

YEAR: 2005
MAKE: FORD
MODEL: FIVE HUNDRED SEL
VIN: 1FAFP27105G184215

Time of auction: December 16, 2024 at 7:00 a.m.
Location: 5009 Parkway Fairfield, AL 35064

BT11/14/2024

_____________________

VEHICLE AUCTION

2009 Chevrolet Impala LT
VIN: 2G1WT57K691143504
Auction will be held December 20, 2024, 7:00 a.m.
Location: 1460 Minor Parkway, Birmingham, AL 35224

BT11/14/2024

______________________________